Shelter and Shade Sail Upgrade Program - Council is seeking tenders from suitably qualified and experienced contractors for the removal, replacement and upgrade of shelters, shade sail structures, picnic facilities and associated landscaping
Removal, replacement and upgrade of shelters, shade sail structures, picnic facilities and associated landscaping Deepwater Park Milperra, Leonard Reserve, Rudd Park Belfield, Wise Reserve Riverwood, Canterbury Park Playground, Roberts Park Early Learning Centre Greenacre, Chester Hill KU Childrens Centre, Earlwood Childrens Centre
AI helper
Council seeks tenders for removal, replacement and upgrade of shelters, shade sails, picnic facilities and landscaping across 8 sites. Compulsory site briefing on 23 Sep 2026. Tenders close 15 Oct 2026 3:00 PM. Electronic lodgement via APET360 only. Requires 5% security, insurances, WHS and environmental plans, quality management, and 3 relevant references. Contract ****, defects liability 12 months, liquidated damages $750/day. Completion by 30 Apr 2027.
Completion date is 30 Apr 2027. The estimated timeframe for delivery is stated as completion date: 30 apr 2027.
Progress claims are due by the end of each month per subclause 37. 1. Interest on overdue payments is 0% per subclause 37. 5.
Respondents must provide details of all warranties proposed. The defects liability period is 12 months per clause 35.
Respondents must provide one of the following current **** certification certificate for WHS, and one of the following current **** certification certificate for quality management.
Liquidated damages are $750 per day per subclause 34. 7. Delay damages are 0% per subclause 34. 9.
Attendance of the compulsory briefing is required. Attendance of briefing is compulsory to complete a compliant submission to this tender opportunity.
Submissions via email are not acceptable. Note: electronic submissions must be lodged via the online questionnaire in 360. email submissions are not acceptable.
Leachate Treatment Plant Scheduled Maintenance Event - Council is seeking Quotations from suitably qualified and experienced Respondents for scheduled maintenance works of the Leachate Treatment Plant ( LTP) at Salt Pan Creek Reserve, Riverwood
Digital Mapping and Route Allocation System for Waste Collection Trucks - T12- 27 Digital Mapping and Route Allocation System for Waste Collection Trucks
Tree Works and Associated Services - Council is seeking Tenders from suitably qualified and experienced Respondents for Tree Works and Associated Services
Shelter and Shade Sail Upgrade Program - Council is seeking tenders from suitably qualified and experienced contractors for the removal, replacement and upgrade of shelters, shade sail structures, picnic facilities and associated landscaping
Shelter and shade sail upgrade Removal, replacement and upgrade of shelters, shade sail structures, picnic facilities and associated landscaping across eight sites.
AI helper
Contractors are sought for the removal, replacement, and upgrade of shelters, shade sail structures, picnic facilities, and landscaping across eight sites in the Canterbury Bankstown LGA. Attendance at a compulsory briefing on Wednesday, September 23rd, 2026, at 10:00 am is required. Tenders must be lodged electronically via APET360 by October 8th, 2026, 3:00 pm. The project completion date is April 30th, 2027.
The completion date for the project is April 30th, 2027.
Payments for progress claims are made by the end of each month.
The certificate shall be issued to contractor pursuant to clause 34. 6 of the as **** general conditions of contract **** subject to the contractor providing asbuilt documentation and warranties.
The general assessment criteria used are capability, methodology, price, organisational capacity, experience, and sustainability.
Respondents must provide a brief history, size, corporate structure, HSR/safety officer details, and any relevant accreditations.
Liquidated damages are 750 per day.
Attendance of briefing is compulsory to complete a compliant submission to this tender opportunity.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
It encompasses all portals in one place.
G. Ferrea
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Efficiency in search times.
R. Chavez
Excellent information. Just what I was looking for.
L. H. Borrelli
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
M. F. Cortez
It's an extremely useful tool.
M. M. Alv
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
It gives me information on tenders that interest me. It's easy to find tenders.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1104 active users, conducted through 09/10/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
