Sub Flooring/ Building Maintenance/ Maintenance Services
****- ****- Lot 205 Depot Road, Saibai ( Bathroom inc. Sub Flooring Upgrade) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refer to the foll
Bathroom upgrade Lot 205 Depot Road, Saibai ( Bathroom inc. sub flooring upgrade)
AI helper
The engagement of services will be awarded to the respondent who best demonstrates the ability to provide best value for money. The contractor must complete the quotation form and response schedules. The lump sum price breakdown schedule must be fully completed. The works are subject to referenced documents including QBuild general terms and conditions. The contractor must ensure minimal disruption to normal tenant requirements and may need to provide temporary facilities if services are unavailable. The contract requires adherence to various Australian standards and local council laws.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.
Sub Flooring/ Building Maintenance/ Maintenance Services
****- ****- Lot 205 Depot Road, Saibai ( Bathroom inc. Sub Flooring Upgrade) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refer to the foll
Bathroom upgrade Lot 205: Depot Road, Saibai ( Bathroom inc. sub flooring upgrade)
AI helper
The engagement of services will be awarded to the respondent who best demonstrates the ability to provide best value for money. The contractor must complete the quotation form and response schedules. The lump sum price breakdown schedule must be fully completed. The contractor is responsible for ensuring minimal disruption to normal tenant requirements and may need to provide temporary facilities if services are unavailable. The contract is subject to referenced documents including QBuild general terms and conditions.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.
If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.
Floor Finishes Upgrade at MSAC and Lakeside Stadium - MSAC conducts annual slip- resistance testing across the facility. Testing undertaken in in February 2024, August and November 2025, and March 2026 confirmed that 47 areas across MSAC and LAKE failed to meet minimum slip- rating standards. Slip- resistance tests have revealed that sections of the existing flooring -- comprising sheet vinyl, stair nosings, coated concrete, and ceramic tiles -- do not meet the required safety classifications. As a result,
Floor finishes upgrade Treatment to areas specifically listed in the attached specification document, removal and disposal of existing floor coverings, removal and disposal of existing stair nosings, supply and installation of new floor coverings, supply and installation of new stair nosings, provision of operation and maintenance manuals for the installed flooring, retesting by Attar Advanced Technology Testing and Research, any additional works or defect rectification to address failed results of retesting.
AI helper
The State Sport Centres Trust intends to treat or replace noncompliant flooring at MSAC and Lakeside Stadium to meet slip-rating standards. The scope includes treatment, removal/disposal of existing floor coverings and stair nosings, supply/installation of new floor coverings and stair nosings, and retesting. Tenderers are not required to provide an estimate for all in-scope floor covering types, but a full scope is preferred. Working with children checks are mandatory for all staff on site.
Sub Flooring/ Building Maintenance/ Maintenance Services
****- ****- Lot 205 Depot Road, Saibai ( Bathroom inc. Sub Flooring Upgrade) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refer to the foll
Bathroom upgrade Lot 205 Depot Road, Saibai ( Bathroom inc. sub flooring upgrade)
AI helper
The engagement of services will be awarded to the respondent who best demonstrates the ability to provide best value for money. The contractor must complete the quotation form and response schedules. The lump sum price breakdown schedule must be fully completed. The contractor is responsible for ensuring minimal disruption to normal tenant requirements and may need to provide temporary facilities if services are unavailable. The contract is subject to referenced documents including QBuild general terms and conditions.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.
If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.
Sub Flooring/ Building Maintenance/ Maintenance Services
****- ****- Lot 205 Depot Road, Saibai ( Bathroom inc. Sub Flooring Upgrade) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refer to the foll
Bathroom upgrade Lot 205 Depot Road, Saibai ( Bathroom inc. sub flooring upgrade)
AI helper
The engagement of services will be awarded to the respondent who best demonstrates the ability to provide best value for money. The contractor must complete the quotation form and response schedules. The lump sum price breakdown schedule must be fully completed. The contractor is responsible for ensuring minimal disruption to normal tenant requirements and may need to provide temporary facilities if services are unavailable. The contract is subject to referenced documents including QBuild general terms and conditions.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.
If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
We selected helpful reviews from real users. Order may change periodically.
Excellent information. Just what I was looking for.
L. H. Borrelli
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
It is complete and optimal, it improves my time.
R. de L. Cruz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Practicality, speed, trust, and credibility—that’s what the work conveys. The information is precise and sharply targeted.
N. De Lima
Excellent platform to help promote and expand the reach of your work.
C. Merino
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
It encompasses all portals in one place.
G. Ferrea
The platform is very user-friendly.
N. Lobato
The email alert is amazing. I really liked the speed — the bid notices arrive by keywords directly in my inbox, which makes searching much easier. I only need to focus on the other processes, which is a big relief.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1095 active users, conducted through 11/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".