This tender is for home modifications work at 294 Yalla Street, Badu Island, Queensland. The project requires ensuring well-equipped facilities with quality fixtures and fittings, adhering to the attached design and construction standards for remote housing. Works are to be quoted for completion during normal hours and must meet the specified requirements. The contractor must provide QBuild supervisor with Safe Work Method Statements (SWMS) for any high-risk work before commencing onsite. The project involves ensuring minimal disruption to tenant requirements and maintaining limited access to facilities where possible. Temporary facilities and services may be required if normal facilities cannot be used or accessed. The contractor is responsible for the health and safety of all persons and property during the works. Key evaluation criteria include best value for money, quoted price, and relevant non-price criteria. Additional documents required include the quotation form and response schedules. The tender closes on May 8, 2026.
The bid notice does not explicitly state a delivery deadline for the completed works. However, it mentions a ime for completion in the Respondent's Declaration section, which should be detailed in the quotation.
The bid notice states that payment will be a lump sum on completion, and progress claims will be considered upon request. The contractor will be paid within 30 days of receiving a valid tax invoice including a breakdown of rates, materials, travel, accommodation, and any other requested information.
The contractor warrants that the works will be free from any charge, liability, or defect, comply with all applicable standards, and be fit for purpose and conform to the description ordered. The contractor must also provide the benefit of any third-party warranties for supplies and warrant that the works do not infringe intellectual property rights. A defect liability period of 12 months from the completion date is specified.
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. The quoted price and relevant non-price criteria will be assessed together to determine the most advantageous outcome for the principal.
The bid notice requires respondents to complete the quotation form and schedules provided. It also mentions that the engagement of services will be awarded to the respondent who best demonstrates the ability to provide best value for money, implying that qualifications related to this ability will be assessed.
The bid notice does not explicitly detail penalties for non-compliance or delays. However, it states that if works are not completed within the requested timeframe, TSIRC nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.
The bid notice indicates attendance at site inspection na under the quotation annexure, suggesting that a formal site inspection is not applicable or mandatory for this tender.
The bid notice does not mention any requirement for sample submission.
The bid notice specifies a supplier query cutoff date of Friday, May 8, 2026, at 04:00 am E. South America Standard Time, which may relate to the deadline for submitting queries or challenges.
The bid notice does not specify an estimated total value for the tender.
