Statewide/Regional Preventative Maintenance - Fire Services ( IS- ****) - Engagement of a single statewide contractor ( or multiple regional contractors) to provide preventative maintenance services for all fire related assets, including electrical generators, switchboards and fire doors across Department of Health and Ambulance Tasmania facilities. Tenderers have the option to tender for either a statewide contract or regional contracts
AI helper
RFT for preventative maintenance of fire assets (generators, switchboards, fire doors) across Tasmanian health facilities. Tenderers may bid for statewide or regional contracts. Closing 28 Oct 2026, 2pm Hobart time. Electronic lodgement only via Tasmanian Government tender website. Contact: ***@***. *. * required. TIPP required if over $5M. Economic and social benefits statement worth 30% of evaluation. Contract from Dec 2026 to Nov 2029 with extension option.
Tenderers must be prequalified under the prequalification scheme. The document states: only contractors prequalified with the department of treasury and finance prequalification scheme are eligible to tender.
Site inspections are possible but not mandatory. The document states: a potential contractor must not inspect a site or sites relevant to the provision of the maintenance services except in accordance with a site inspection arranged by the potential contractor with the contact officer.
Tenders may be excluded for late submission or non-compliance. The document states: a tender that is received after the closing time will not be eligible for evaluation and failure to comply with the conditions for participation. . . will result in a tender being ineligible for evaluation.
Rye Fire Station - Alterations & Additions - To seek tenders from suitable building contractors to construct Alterations and Additions to the Rye Fire Station at 21 Collingwood Street, Rye, VIC **** includes: Demolition of the existing Motor Room, Offices, Turnout Room, Amenities and Training Room, including masonry wall to east boundary. Construction of a new shed including a 3 bay Motor Room with motorised bi- fold doors, motor room ventilation and a Comms Alcove. Construction of a timber framed st
AI helper
Fixed price lump sum contract for alterations and additions to Rye Fire Station. Tenders must be lodged electronically via Tenders Victoria by 2:00 PM on 30 October 2026. Evaluation criteria: experience and capability 40%, resource capacity 40%, program 15%, social and environmental benefits 5%, OHS compliance mandatory, price lowest acceptable. Completion within 110 working days, latest by mid-July 2027. Site inspection to be requested via Tenders Victoria forum.
The latest date for completion of the works is mid-July 2027, with a nominated period of 110 working days. the principals nominated period for completion of the works is 110 working days
The evaluation criteria include non-price criteria and price, with the price criterion being lowest acceptable tender. price lowest acceptable tender
Tenderers must complete the OHS questionnaire and may need to provide evidence of OHS certification or complete the assessment checklist. tenderers are required to complete table 1
Tenderers are required to inspect the site prior to submitting tenders, with site inspection to be requested via Tenders Victoria. tenderers are required to acquaint themselves with all matters relating to the proposed contract and to inspect the site
Tenders that do not comply with requirements may be rejected, and late submissions will not be accepted. any tender that does not comply with any requirement of the tender documents. . . may be rejected
**** | Self- Bunded Fuel Tanks Supply & Delivery- Alexandrina Council invites Quotes from Respondents to Supply and Deliver 2 Self- bunded fuel tanks for fuel storage at the Goolwa and Strathalbyn Works Depots. The Respondent shall provide the Goods in accordance with the Specifications contained within Section C of the attached documentation and Council will enter into an Agreement for Goods with the successful Respondent .
Supply and delivery of 2 self- bunded fuel tanks for fuel storage at the Goolwa and Strathalbyn works depots 2 self- bunded fuel tanks, minimum diesel storage **** maximum ****, AdBlue storage ****, self- bunded double wall, 3 bulk fill points with overfill protection valves and alarms, fold out access ladders, calibrated dipsticks and level gauge, domed roof, safety signage, lockable pump bay with container steel doors and locks, 240V diesel driven pumps, AdBlue pump, 20m heavy duty retractable hose reels, emergency stop, fuel management system, retractable breakaway couplings, spill kits and fire extinguishers, card recorder integrated with council' s current system
AI helper
Supply and deliver 2 self-bunded fuel tanks to Goolwa and Strathalbyn works depots. Quotes must be lodged electronically via Vendor Panel or SA Tenders before 2:00pm Adelaide time on 9 October 2026. Prices must be lump sum, fixed, include GST and all delivery costs. Evaluation criteria include local economic benefit (30%), implementation (10%), value added services (10%), and warranty (50%). Delivery required by 30 June 2026. Contact Simon Morris via email only.
Goods are required to be delivered/installed by 30 June 2026. The RFQ states: goods are required to be deliveredinstalled by 30 june 2026.
Respondents must detail any extended warranties offered. The RFQ states: please indicate if there are any warranties, including any conditions andor exclusions outside of the standard twelve 12 month warranty.
Respondents must complete all schedules including financial capacity, licences, and insurance. The RFQ states: all forms must be completed in order for the quote to be considered by the council as a conforming quote.
Quotes received after the closing date will not be considered. The RFQ states: quotes received after the closing date will not be considered.
Preferred Supplier Panel for Minor Building Construction, Repairs and Maintenance - This document outlines the terms and conditions for suitably qualified and experienced Contractors for the " Provision of Minor Building Construction and Maintenance". Townsville City Council ( Principal) seeks to engage a panel of qualified and experienced contractors to deliver minor building construction, repairs, maintenance and associated specialist building services as defined in PSA00297. The proposed contract term of
Minor building construction, repairs and maintenance Minor building construction, repairs, maintenance, associated specialist building services, minor capital works, reactive maintenance, emergency response works, renovations, structural repairs, general handyman services, small- scale infrastructure projects, building certification, statutory compliance inspections, building condition assessments, design review, drafting services, budget estimates, repair methodologies, engineering advice, technical reporting, specialist consultancy services relating to structural, hydraulic, mechanical, fire and aquatic infrastructure, supply, installation, maintenance and repair of commercial flooring systems ( vinyl, carpet, epoxy coatings, polishing, sanding), supply, installation, maintenance and repair of glazing and aluminium systems ( windows, doors, shopfronts, emergency glass replacement), supply, installation and maintenance of blinds, awnings, drapes, tinting, frosting and associated window covering systems, furn
AI helper
Townsville City Council seeks qualified contractors for minor building construction, repairs, and maintenance over a 3-year term (extendable by 2 years). Services include general construction, specialist compliance, flooring, glazing, window coverings, and furniture relocation. Suppliers must meet CMS requirements, ensure worker qualifications are current, and adhere to WHS and environmental policies. Invoices must be submitted to ***@***. *. * and paid within 30 days.
Invoices must be submitted to ***@***. *. * and will be paid within 30 days from invoice receipt date. invoices must be submitted to ***@***. *. * and will be paid within 30 days from invoice receipt date.
Suppliers must ensure personnel hold applicable licences and qualifications, and must meet the principal's contractor management system requirements. The supplier must ensure that the works hold any applicable licences and qualifications required to carry out the obligations of the contract.
Failure to meet KPIs may result in performance management actions, including suspension or removal from the panel. continued nonperformance may result in: removal from the paneltermination of the contract in accordance with contract conditions.
Noncompliances with health, safety, or environmental requirements may lead to contract termination and exclusion from further work. noncompliances, including oneoff instances or continuous breaches of health, safety and environmental requirements may lead to the termination of a contract and exclusion from further work being awarded by the principal.
Preferred Supplier Panel for Minor Building Construction, Repairs and Maintenance - This document outlines the terms and conditions for suitably qualified and experienced Contractors for the " Provision of Minor Building Construction and Maintenance". Townsville City Council ( Principal) seeks to engage a panel of qualified and experienced contractors to deliver minor building construction, repairs, maintenance and associated specialist building services as defined in PSA00297. The proposed contract term of
Minor building construction, repairs and maintenance Minor building construction, repairs, maintenance, associated specialist building services, minor capital works, reactive maintenance, emergency response works, renovations, structural repairs, general handyman services, small- scale infrastructure projects, building certification, statutory compliance inspections, building condition assessments, design review, drafting services, budget estimates, repair methodologies, engineering advice, technical reporting, specialist consultancy services relating to structural, hydraulic, mechanical, fire and aquatic infrastructure, supply, installation, maintenance and repair of commercial flooring systems ( vinyl, carpet, epoxy coatings, polishing, sanding), supply, installation, maintenance and repair of glazing and aluminium systems ( windows, doors, shopfronts, emergency glass replacement), supply, installation and maintenance of blinds, awnings, drapes, tinting, frosting and associated window covering systems, furn
AI helper
Townsville City Council seeks qualified contractors for minor building construction, repairs, and maintenance over a 3-year term (extendable by 2 years). Services include general construction, specialist compliance, flooring, glazing, window coverings, and furniture relocation. Contractors must comply with WHS requirements, including registration in the principal's CMS. Invoices must be submitted to ***@***. *. * and paid within 30 days. The submission deadline is 16 October 2026.
Invoices must be submitted to ***@***. *. * and will be paid within 30 days from invoice receipt date. invoices must be submitted to ***@***. *. * and will be paid within 30 days from invoice receipt date.
Contractors must ensure all required licences and qualifications remain valid and current throughout the term of the contract. it is the responsibility of the contractor to ensure that all required licences and qualifications remain valid and current throughout the term of the contract.
Failure to meet required standards may result in performance management actions, including formal corrective measures and adjustments to future work allocation. failure to meet required standards may result in the application of performance management actions, including formal corrective measures and adjustments to future work allocation.
Noncompliances may lead to the termination of a contract and exclusion from further work being awarded by the principal. noncompliances, including oneoff instances or continuous breaches of health, safety and environmental requirements may lead to the termination of a contract and exclusion from further work being awarded by the principal.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
It encompasses all portals in one place.
G. Ferrea
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Efficiency in search times.
R. Chavez
Excellent information. Just what I was looking for.
L. H. Borrelli
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
M. F. Cortez
It's an extremely useful tool.
M. M. Alv
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
It gives me information on tenders that interest me. It's easy to find tenders.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1104 active users, conducted through 09/10/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".