This is a public tender for home modification upgrades at 68 Louis Road, Hammond Island, QLD 4875. The project is managed by the Torres Strait Island Regional Council (TSIRC) Building Services Unit. The tender closes on May 15, 2026. The evaluation process will consider both price and non-price criteria to determine the best value for money. Respondents must complete the quotation form and schedules provided. Referenced documents include QBuild General Terms and Conditions, QBuild Specification, and Residential Product Standards. The contractor is responsible for obtaining all necessary permits and paying associated costs, including those related to working on Torres Strait Island land. Work must be carried out by experienced and licensed personnel. The contractor must adhere to strict environmental and work health and safety regulations. Payment will be lump sum on completion, with progress claims considered upon request. A defect liability period of 12 months is required. Insurance requirements include public and product liability of $20,000,000.
The bid notice does not explicitly state a delivery deadline for the completed works. However, the quotation validity period is 90 days.
The bid notice states that payment will be a lump sum on completion, and progress claims will be considered upon request. The contractor will be paid within 30 days of receiving a valid tax invoice. The contractor's lump sum price breakdown is fixed and inclusive of all taxes, including GST, insurance, freight, staff travel, accommodation, and delivery costs.
The contractor warrants that the works will be free from any charge, liability or defect, comply with all applicable standards, and be fit for purpose and conform to the description ordered. The contractor must also provide TSIRC with the benefit of any third-party warranties for the supplies. The defect liability period is 12 months from the completion date.
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. The quoted price and relevant non-price criteria will be assessed together to determine the most advantageous outcome for the principal.
The bid notice requires that all work must be carried out by experienced and licensed personnel in the field of work specified. Respondents must also provide an overview of their experience and past performance in projects of similar nature, scope, and size.
The bid notice mentions that if works are not completed within the requested timeframe, TSIRC nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. If the contractor fails to provide any agreed deliverable, or complete any agreed milestone, they must use all reasonable endeavors to correct the issue at no additional cost to TSIRC.
The bid notice indicates attendance at site inspection na, which suggests that a site inspection is not applicable or not mandatory.
The bid notice does not mention any requirement for sample submission.
The supplier query cutoff date is Friday, 15 May 2026, 04:00 am E. South America Standard Time. This is the deadline for submitting supplier queries, which may relate to challenging aspects of the tender.
