Hydrant Valve Tenders

The contractor warrants that its design and the completed works will satisfy this ppr. The contractor warrants that its design and the completed works will satisfy this ppr.

Tenders will be evaluated against weighted criteria, with financial tendered price being 40. 0%. evaluation criteria weighting. . . e financial tendered price and or schedule of rates if applicable 40. 0

Invitees must submit several documents, including HSW prequalification, insurance policies, and management systems. question 2 requiredhave you submitted attachment 1 hsw prequalification. docx

Site inspections are optional, and a briefing session is optional. briefing session optional

Failure to attend a mandatory briefing session, site inspection, or other specified occasion will disqualify the invitee. if an invitee fails to attend a mandatory briefing session, site inspection or other specified occasion, council will, unless there are extenuating circumstances, disqualify the invitee from further participating in the process.

The quotation closing date is September 2, 2026, at 2pm. quotation closing 2 september 2026 date quotation closing 2pm

Payment milestones are proposed as: 20% for preliminaries/supply, 30% for installation/construction, and 50% for commissioning/final report. milestone description proposed number: 1 preliminaries, site establishment, supply delivery 20 2 installation and construction works 30 3 commissioning and final report documentation 50

Quotations will be assessed based on mandatory compliance, work health and safety systems, performance, weighted price evaluation, experience, capability, proposed personnel, timeframe, construction methodology, local content, and modern slavery mitigation. quotations will be assessed in accordance with the following criteria: mandatory compliance with the quotation requirements criteria respondents are requested to provide certain information within their submissions and may be asked to adhere to other requirements e. g. attendance at meetings. work health and safety systems and performance weighted price evaluation experience and capability criteria proposed personnel timeframe for completion of the project constructionperformance methodology local content modern slavery mitigation maturity

Contractors must have an appropriate NSW plumbing and drainage contractor licence if water service connections are undertaken, demonstrated competency in water reticulation construction, and current general construction induction white card. appropriate nsw plumbing and drainage contractor licence where water service connections are undertaken. demonstrated competency in the construction of water reticulation infrastructure.

FALSE

The quotation closing date is September 2, 2026, at 2pm. quotation closing 2 september 2026 date quotation closing 2pm

Payment milestones are proposed as: 20% for preliminaries/supply, 30% for installation/construction, and 50% for commissioning/final report. milestone description proposed number: 1 preliminaries, site establishment, supply delivery 20 2 installation and construction works 30 3 commissioning and final report documentation 50

Quotations will be assessed based on mandatory compliance, work health and safety systems, performance, weighted price evaluation, experience, and capability. quotations will be assessed in accordance with the following criteria: mandatory compliance with the quotation requirements criteria respondents are requested to provide certain information within their submissions and may be asked to adhere to other requirements e. g. attendance at meetings. work health and safety systems and performance weighted price evaluation experience and capability criteria

Contractors must have an appropriate NSW plumbing and drainage contractor licence if water service connections are undertaken, and demonstrated competency in water reticulation infrastructure construction. appropriate nsw plumbing and drainage contractor licence where water service connections are undertaken. demonstrated competency in the construction of water reticulation infrastructure.

FALSE