**** Caloundra Headland Coastal Pathway and Civil Works - Section B - Sunshine Coast Council is seeking a suitably qualified Principal Contractor to construct a section of coastal pathway along the Esplanade Headland, Kings Beach. The section of pathway stretches approximately 200 linear metres and comprises of a concrete pathway, retaining walls and car park works. The scope of work includes, but is not limited to: o Concrete pathway construction; o Drainage construction; o Landscape works ( hardscape,
Construction of a coastal pathway section along Esplanade Headland, Kings Beach, including concrete pathway, retaining walls and car park works Concrete pathway construction, drainage construction, landscape works ( hardscape, furniture installation and planting), lighting and electrical work, installation of memorial plaques, traffic and pedestrian management, site management including environmental and WHS, subcontractor management, maintenance and defects liability period
AI helper
Sunshine Coast Council seeks a principal contractor for a coastal pathway section at Kings Beach, approximately 200 linear metres, including concrete pathway, retaining walls, car park works, drainage, landscaping, lighting, electrical work, memorial plaques, traffic management, and site management. Lump sum contract, commencement early February 2027, functional completion by 30 June 2027. Tenders close 12noon 27 October 2026 (website shows 2 November 2026). Site information session on 8 October 2026 at Centaur Park carpark, registration required. Evaluation criteria: capability 25%, methodology 20%, social/economic 20%, price 35%. Tenders via VendorPanel. Clarification cutoff 3 business days before closing.
Functional completion is required by 30 June 2027. The contract has an anticipated commencement of early February 2027. As stated: functional completion required by 30 june 2027.
The evaluation criteria are: capability and experience 25, methodology 20, social and economic factors 20, price 35.
A site information session will be held on 8 October 2026 at 11:00am at carpark at centaur park, opposite 18 esplanade headland, kings beach. Registration required via email.
Requests for clarification will not be accepted on or after the date that is 3 business days prior to the closing date.
Prohibited contact with council employees or elected members may result in disqualification: any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process.
**** Caloundra Headland Coastal Pathway and Civil Works - Section B - Sunshine Coast Council is seeking a suitably qualified Principal Contractor to construct a section of coastal pathway along the Esplanade Headland, Kings Beach. The section of pathway stretches approximately 200 linear metres and comprises of a concrete pathway, retaining walls and car park works. The scope of work includes, but is not limited to: o Concrete pathway construction; o Drainage construction; o Landscape works ( hardscape,
Construction of a section of coastal pathway along the Esplanade Headland, Kings Beach, including concrete pathway, retaining walls and car park works Concrete pathway construction, drainage construction, landscape works ( hardscape, furniture installation and planting), lighting and electrical work, installation of memorial plaques, traffic and pedestrian management, site management including environmental and WHS, subcontractor management, maintenance and defects liability period
AI helper
Sunshine Coast Council seeks a principal contractor for a coastal pathway section at Kings Beach, approximately 200 linear metres, including concrete pathway, retaining walls, car park works, drainage, landscaping, lighting, and memorial plaques. Lump sum contract, commencement early February 2027, functional completion by 30 June 2027. Tenders due 12noon 27 October 2026 (or 2 November 2026 per website) via VendorPanel. Site information session on 8 October 2026 at Centaur Park carpark, registration required. Evaluation criteria: price 35%, capability 25%, methodology 20%, social/economic 20%. Clarification cutoff 3 business days before closing. Prohibited contact with council employees may lead to disqualification.
Functional completion is required by 30 June 2027. The contract states: functional completion required by 30 june 2027.
The evaluation criteria include price at 35% weighting. The document states: evaluation criteria weighting capability and experience 25methodology 20social and economic factors 20price 35.
A site information session is scheduled. The document states: date and time: 11: 00am, 8 october 2026address: carpark at centaur park, opposite 18 esplanade headland, kings beach.
Clarification cutoff is 3 business days before closing. The document states: clarifications cutoff for requests for clarification or further information will not be accepted clause 3. 10 of the pt on or after the date that is 3 business days prior to the closing date.
Prohibited contact may lead to disqualification. The document states: any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process.
**** - Lockyer Avenue Stage 1B - Resurfacing SLK 0. 33- 0. 65 - As per the Request for Tender documents.
Road resurfacing works on Lockyer Avenue Stage 1B SLK 0. 33- 0. 65 Civil works for road reconstruction, traffic management, additional lighting, site supervision, road surface maintenance, pedestrian access maintenance, delivery access maintenance, notices to residents and businesses, noise management plan, spoil handling and disposal, cold planed material stockpiling
AI helper
City of Albany seeks a qualified contractor for road resurfacing works on Lockyer Avenue Stage 1B. Works must be undertaken at night (6pm-6am AWST). Mandatory site inspection on 23 October 2026 at 9:00am AWST at corner of Lockyer Avenue and Young Street. Tender deadline: 10:00am AWST, 12 November 2026. Practical completion by 30 April 2027. Contractor responsible for traffic management, lighting, site supervision, noise management plan, spoil disposal, and stockpiling cold planed material at city depot. Evaluation based on best value for money. Prices fixed on schedule of rates/lump sum basis. Public liability and product liability insurance of $20 million required.
Practical completion is to be achieved before Friday 30th April 2027. The contract shall be completed at the end of the defects liability period twelve months from award of practical completion.
Prices tendered are to be on a schedule of rate/lump sum basis. All prices are to be fixed for the term of the contract. Tendered prices must include GST and all applicable levies, duties, taxes, and charges.
Contractors shall state in their quotation the period of warranty and guarantee conditions that apply against defects for the goods offered, together with any aftersales services provided.
The principal has adopted a best value for money approach to this request. This means that, although price is considered, the offer containing the lowest price will not necessarily be accepted.
Offers are assessed against the responses to the selection criteria and shall be scored in accordance with the table. Failure to provide the specified information may result in elimination from the tender evaluation process or a low score.
There is a tender site inspection. Attendance at this meeting is mandatory. Tenderers are requested to attend a site inspection on Friday, 23 October 2026 at 9:00am AWST at the corner of Lockyer Avenue and Young Street intersection.
The cut off for queries is **** AWST on Thursday 5 November 2026 in order give all tenderers sufficient time to address additional information.
Failure to attend a briefing/site inspection will render the tenderer ineligible to tender. Offers that do not contain all information requested as per selection criteria will be excluded from evaluation.
Outdoor Lighting Installation/ Electrical And Lighting Maintenance
**** Caloundra Headland Coastal Pathway and Civil Works - Section B - Sunshine Coast Council is seeking a suitably qualified Principal Contractor to construct a section of coastal pathway along the Esplanade Headland, Kings Beach. The section of pathway stretches approximately 200 linear metres and comprises of a concrete pathway, retaining walls and car park works. The scope of work includes, but is not limited to: o Concrete pathway construction; o Drainage construction; o Landscape works ( hardscape,
Construction of a coastal pathway section, retaining walls and car park works at Caloundra Headland, Kings Beach Concrete pathway construction, drainage construction, landscape works ( hardscape, furniture installation and planting), lighting and electrical work, installation of memorial plaques, traffic and pedestrian management, site management including environmental and WHS, subcontractor management, maintenance and defects liability period
AI helper
Sunshine Coast Council seeks a principal contractor for a coastal pathway section at Kings Beach, approximately 200 linear metres, including concrete pathway, retaining walls, car park works, drainage, landscaping, lighting, and memorial plaques. Lump sum contract, commencement early February 2027, functional completion by 30 June 2027. Tenders due 12noon 27 October 2026 (website shows 2 November 2026). Site information session on 8 October 2026 at Centaur Park carpark, registration via email. Evaluation criteria: price 35%, capability 25%, methodology 20%, social/economic 20%. Tenders via VendorPanel. Clarification cutoff 3 business days before closing.
Functional completion is required by 30 June 2027. The contract states: functional completion required by 30 june 2027.
The evaluation criteria include price at 35% weighting. The document states: evaluation criteria weighting capability and experience 25methodology 20social and economic factors 20price 35.
A site information session is scheduled. The document states: date and time: 11: 00am, 8 october 2026address: carpark at centaur park, opposite 18 esplanade headland, kings beach.
Clarification cutoff is 3 business days before closing. The document states: clarifications cutoff for requests for clarification or further information will not be accepted clause 3. 10 of the pt on or after the date that is 3 business days prior to the closing date.
Prohibited contact with council employees or elected members may lead to disqualification. The document states: any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process.
**** Caloundra Headland Coastal Pathway and Civil Works - Section B - Sunshine Coast Council is seeking a suitably qualified Principal Contractor to construct a section of coastal pathway along the Esplanade Headland, Kings Beach. The section of pathway stretches approximately 200 linear metres and comprises of a concrete pathway, retaining walls and car park works. The scope of work includes, but is not limited to: o Concrete pathway construction; o Drainage construction; o Landscape works ( hardscape,
Construction of a section of coastal pathway along the Esplanade Headland, Kings Beach, including concrete pathway, retaining walls and car park works Concrete pathway construction, drainage construction, landscape works ( hardscape, furniture installation and planting), lighting and electrical work, installation of memorial plaques, traffic and pedestrian management, site management including environmental and WHS, subcontractor management, maintenance and defects liability period
AI helper
Sunshine Coast Council seeks a principal contractor for a coastal pathway section at Kings Beach, approximately 200 linear metres, including concrete pathway, retaining walls, car park, drainage, landscape, lighting, and electrical works. Lump sum contract, commencement early February 2027, functional completion by 30 June 2027. Tenders due 12noon 27 October 2026 (website shows 2 November 2026). Site information session on 8 October 2026 at Centaur Park carpark, registration required via email. Evaluation criteria: price 35%, capability and experience 25%, methodology 20%, social and economic factors 20%. Tenders submitted electronically via VendorPanel. Clarification cutoff 3 business days before closing.
Functional completion is required by 30 June 2027, as stated: functional completion required by 30 june 2027.
The evaluation criteria include price at 35% weighting, as stated: price 35.
A site information session will be held on 8 October 2026 at Centaur Park carpark, as stated: site information session will be held in accordance with the details provided in schedule 2.
Clarification cutoff is 3 business days prior to closing date, as stated: clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
Prohibited contact with council employees or elected members may lead to disqualification, as stated: any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 30.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
