Sewer Line Tenders

The works must be completed by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use. progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.

Contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection. contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor WHS systems, availability, and local contractor. submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

Contractor must have the necessary skills and expertise to supply the scope of works. the necessary skills and expertise to be able to competently supply the scope of works.

A portion of each progress payment, equivalent to 10% of the value of work completed exclusive of GST, shall be retained by council as retention money. a portion of each progress payment, equivalent to 10 of the value of work completed exclusive of gst, shall be retained by council as retention money.

There is no mandatory site visit for these works but requests for a site visit during the tender period are welcome. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Supplier query cutoff is Wednesday 04 November 2026 03:00 am. supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time.

Any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

The deadline is 4pm EST, Wednesday 4th November 2026. tender closing openingsubmissions shall be lodged on or before the closing time of 4pm est, wednesday 4th november 2026.

The contractor must provide a 12?month warranty on workmanship from practical completion. the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Submissions are assessed on price, past performance, technical expertise, WHS, availability, and local contractor. submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

Contractor must have necessary skills and expertise. the necessary skills and expertise to be able to competently supply the scope of works.

Failure to maintain progress may result in liquidated damages. failure to maintain progress in accordance with the approved project schedule, where the delay has not been approved by the principal and is not otherwise permitted under the contract, may constitute a breach of the contract and may result in the application of liquidated damages.

No mandatory site visit; requests welcome. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Direct contact outside approved channel leads to automatic disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

closes tuesday 27 october 2026 11: 00 pm e. south america standard time

Completion of all works, including commissioning, is required by 17 December 2027. The document states: completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site or materials delivered to site. The document states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.

The contractor must provide a 12-month warranty on all workmanship from practical completion. The document states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Contractors must have necessary skills and expertise, and complete a WHS questionnaire. The document states: the contractor warrants that it has the necessary skills and expertise to be able to competently supply the scope of works.

Failure to maintain progress may result in liquidated damages. The document states: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.

There is no mandatory site visit, but requests are welcome. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Direct contact with council employees, councillors, or consultants is prohibited and will result in automatic disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

Completion of all works, including commissioning, is required by 17 December 2027. Respondents must provide a schedule of works with their submission. completion of all components of the works, including commissioning, is required by 17 december 2027

Progress claims may be submitted for works fully executed on site or materials delivered to site. A portion of each progress payment, equivalent to 10% of the value of work completed, will be retained. a portion of each progress payment, equivalent to 10 of the value of work completed exclusive of gst, shall be retained by council as retention money

The contractor must provide a 12-month warranty on all workmanship from the date of practical completion. the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection

Contractors must have necessary skills and expertise, complete a WHS questionnaire, and provide details of relevant experience on similar projects in the last 5 years. the contractor warrants that it has the necessary skills and expertise to be able to competently supply the scope of works

Failure to maintain progress may result in liquidated damages. Noncompliance may lead to suspension or termination of contract. failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages

There is no mandatory site visit, but requests for a site visit during the tender period are welcome. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome

Any form of canvassing or direct contact with council employees, councillors, or consultants is strictly prohibited and will result in automatic disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process