This tender is for the full delivery of road upgrade works along Diamond Gully Road, including site management, mobilization, traffic and construction management planning, and all required permits. The contractor will undertake survey setout, site preparation, vegetation removal, earthworks, underground service installation, pavement removal, subgrade preparation and full road pavement construction. Works also include stormwater drainage installation, asphalt and spray sealing, signage and line marking, protection of existing utilities, construction of a shared footpath with TGSI, fencing and handrailing, as well as installation of public lighting. The contractor is responsible for reinstating all disturbed areas and ensuring safe, compliant delivery of all components of the project. Respondents are required to complete an OHS management system questionnaire and provide supporting documentation, including insurance certificates and sample safety documents. A statutory declaration regarding tender price disclosure and genuine competition is also required.
The bid notice does not explicitly state a delivery deadline for the completed works. However, it mentions a date for practical completion to be inserted upon award and a defects liability period of 12 months.
The bid notice specifies an interest rate on overdue payments of 18% per annum, as per subclause 37. 1.
The bid notice mentions a defects liability period of 12 months, as per clause 35.
The bid notice does not explicitly state the award criterion.
Respondents will be required to verify their responses noted in their OHS management system questionnaire by providing evidence of their ability and capacity in relevant matters. This includes providing documentation for public liability insurance, workers compensation insurance, sample safety documents, a sample traffic management plan, evidence of operator licensing and competency, construction induction or red card training, traffic control licenses, and evidence of plant and equipment maintenance systems, as well as a sample risk assessment.
The bid notice specifies liquidated damages at a rate of $410 per day, as per subclause 34. 7.
The bid notice does not explicitly mention a site visit requirement.
The bid notice requires submission of sample safety documents relevant to the contract scope of work, including but not limited to protection of the public, working in the vicinity of overhead and underground services, personal protective equipment, worksite induction, worksite safety inspection, hazardous substances/dangerous goods including asbestos management, working adjacent to roadways and movement of powered mobile plant. A sample traffic management plan relevant to this scope of work is also required.
The bid notice does not explicitly state a challenge deadline.
