Construction - Tiri Bridge Replacement - In May 2025 MidCoast Council ( MCC) encountered a record breaking flood event severely impacting critical infrastructure which is now eligible for replacement under the NSW Reconstruction Authority ( NSW RA) guidelines. MCC has completed detailed investigations, designs, TfNSW specifications, and now seeks tender from suitably qualified and experienced civil contractors to replace Tiri Bridge Tiri NSW **** bridge is located approx. 50min drive west of Taree spa
Tiri Bridge Replacement construction works Bridge replacement including bored concrete piles, cast in situ headstocks and abutments, precast planks, approach roads, demolition and removal of existing bridge, scour protection, drainage, pavement, roadworks, environmental rehabilitation
AI helper
Tender for Tiri Bridge replacement in NSW. Mandatory pre-tender briefing and site inspection on 15/10/2026 at 10:30 AM at Tiri Road, Knorrit Flat. Tenders close 14:00 on 11/11/2026 via VendorPanel. Mandatory criteria include insurance, briefing attendance, and TfNSW prequalification at financial level F5 or higher. Evaluation based on technical criteria and price. Contract term to be nominated by tenderer. Contact Adam Grant via VendorPanel forum.
The tenderer must nominate its proposed contract duration and date for completion in the tender program. Subject to council's acceptance, the agreed date for completion will be recorded in the contract information and will become contractually binding upon award of the contract.
Tenderers must satisfy all mandatory assessment criteria. Failure to satisfy a mandatory assessment criterion may result in the tender being excluded from further evaluation. Mandatory criteria include TfNSW prequalification at financial level F5 or higher, with demonstrated compliance with TfNSW G1 clause 12.
Mandatory pre-tender briefing including site inspection on 15/10/2026 at 10:30 AM at Tiri Road, Knorrit Flat, NSW **** specific PPE requirements: standard construction site PPE hi viz, steel cap boots, sun protection etc. Mandatory attendance: yes.
Any tenderer who solicits support for its tender or otherwise seeks to influence the outcome of the tender process may, at council's discretion, be disqualified from any further involvement in this tender process.
**** RFT Prince Edward Park Pedestrian Bridge Design and Construct - Sutherland Shire Council invites suitably qualified and experienced contractors to tender for the Prince Edward Park Woronora Pedestrian Bridge Renewal Project. The project involves the demolition of the existing pedestrian bridge and the construction of a new bridge to provide a safe, compliant, and durable pedestrian and cyclist crossing over the Woronora River. The works also include the construction of new shared pedestrian and bicyc
AI helper
Design and construct pedestrian bridge renewal over Woronora River. Mandatory site briefing on 20 Oct 2026 at Prince Edward Park carpark, RSVP required. Tender closes 27 Nov 2026. Mandatory criteria: experience in pedestrian bridge design/construction, at least two similar bridge projects, and civil marine construction experience. Contract sum is lump sum, security 5% via bank guarantees, liquidated damages $3,900/day, defects liability 24 months, PI insurance $10M, public liability $20M.
Tenderers must demonstrate relevant experience in the design and construction of pedestrian bridges, at least two bridge infrastructure projects of similar scale, and civil marine construction experience. tenderers must demonstrate relevant experience in the design and construction of pedestrian bridges
Liquidated damages are set at $3,900 per day for delay. liquidated damages, 3, 900 per day rate
Mandatory site briefing required. mandatory site briefing will be required. meeting location is at prince edward park carpark off prince edward park rd woronora nsw. @11am on 20th oct 2026
Submissions not meeting mandatory criteria will not be evaluated. submissions that do not satisfy these requirements will not proceed to evaluation for award
PASC- 2026- 005 Pormpuraaw ASC - Register of Preferred Suppliers ( EOI) - See attached " expression of Interest ( EOI) /Invitation to Tender.
Register of preferred suppliers ( EOI) for the supply of goods and services to Pormpuraaw Aboriginal Shire Council Accommodation, airport line marking, annual electrical inspection, architects and designers, asbestos removal, auto electrical, automotive air conditioning, automotive detailing, block layers, builder, carpenters, cabinet makers, joiners, catering, CCTV and air bridge installation, chlorine maintenance, cleaning, concrete cutting, concreters, cultural monitoring, diesel fitting, demolition, engineering consultants, financial services, fencing, floor laying, fire equipment maintenance, handyperson services, glazing, human organisation change, helicopter hire, lawn mowing, landscaping, locksmith, legal services, metal fabrication welding, mobile workshop, media and graphic design, paving, mural and painting artists, plant hire, painting, plasterers, pest control, project management, plant mechanical labour, removalist, plumbers, irrigation, gas fitter, quarry materials, road base, aggregates, crush
AI helper
EOI for inclusion on Pormpuraaw Aboriginal Shire Council's Register of Preferred Suppliers for goods and services across numerous categories. Closing date: 4 November 2026, 5pm. Evaluation criteria: pricing (30%), insurance/quality/financial capacity (20%), experience/technical/managerial capacity (20%), local supplier (30%). Register term: 2 years with possible 12-month extension. No guarantee of work. Suppliers must demonstrate technical, financial and managerial capability. Local supplier preference applies. Submit via email to tenders@pormpuraaw. qld. gov. au.
Council will pay invoices within 30 days from the end of month in which the invoice is received, as stated: council will pay the amount of the invoices issued by the supplier under clause 11c within 30 days from the end of month in which the invoice is received.
The supplier warrants goods will be new, of merchantable quality and free from defects in materials and workmanship and services performed with skill, due care, and diligence and by appropriately qualified, licenced, skilled and trained personnel.
Evaluation criteria: pricing schedule of rates 30, insurance quality financial capacity 20, experience technical managerial capacity 20, local supplier 30.
Suppliers must demonstrate the technical, financial and managerial capability necessary for the categories of goods andor services for which inclusion is sought, together with an ability to meet councils requirements in a remote regional community.
Council may reject tenders that are nonconforming, alternative, or late, or if the tenderer has breached a warranty given or representation made pursuant to these conditions of tendering.
West Moreton Bridge Renewal Stage 2 - Queensland Rail is seeking to engage a Principal Contractor to deliver the West Moreton Bridge Renewal Stage 2 Project under a Design & Construct ( D& C) delivery model. The project involves the replacement of four existing timber rail bridges at two locations on the Rosewood to Toowoomba section of the West Moreton System, at chainages **** km and **** km. The works will broadly include the design and construction of new concrete ballast deck bridges, demolition
AI helper
Queensland Rail seeks a principal contractor for the West Moreton Bridge Renewal Stage 2 project under a design and construct model. The project involves replacing four timber rail bridges with concrete ballast deck bridges at two locations on the Rosewood to Toowoomba section. Works include design, construction, demolition, track, formation, drainage, and access works within a live rail environment. Mandatory online briefing on 30 October 2026 and mandatory site inspection on 5 November 2026. Tenders must be submitted via Ariba sourcing system by 11:00am AEST on 4 December 2026. Payment is lump sum. Evaluation based on overall value for money considering multiple criteria including price, local supply chain, and social objectives.
The basis for payment is lump sum, as stated: basis for payment lump sum.
Queensland Rail will evaluate tenders based on overall value for money, as stated: queensland rail will evaluate tenders based on overall value for money.
The site inspection is mandatory, as stated: the site inspection is mandatory for participation in the tender process.
**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
Weir tower access walkway replacement Replacement of existing elevated walkway to access weir tower during flood inundation events, removal and demolition of existing structural steel walkway including platform and handrails, maintenance and remediation of existing steel trestles including abrasive blasting and painting
AI helper
Tenders invited for replacement of existing elevated walkway to weir tower, including demolition of existing structural steel walkway, platform and handrails, and remediation of steel trestles via abrasive blasting and painting. Contract is lump sum or schedule of rates per **** completion due 25 March 2027. Liquidated damages $500 per day. Defects liability period 12 months. Security: two unconditional bank guarantees at 5% of contract sum. Public liability insurance minimum $20,000,000. Contact Paul Weston at 07 **** **** closes 24 November 2026.
Practical completion is due by 25th March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts. The contract states: payment period means: if the contract is a building contract, 15 business days.
Tenders are invited from suitably qualified respondents and the contract requires standard risk prequalified suppliers for the weir tower access walkway replacement project.
Liquidated damages are set at $500 per day for delay, as stated in the annexure: liquidated damages, rate subclause 34. 7 500 per day.
We selected helpful reviews from real users. Order may change periodically.
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
M. F. Cortez
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
It is complete and optimal, it improves my time.
R. de L. Cruz
Excellent information. Just what I was looking for.
L. H. Borrelli
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I liked the way they search for tenders and provide us with the link to view them.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Plans start at A$ 30.00/month, with options for different needs and subscription terms. Plans are prepaid: check the total amount and duration before confirming. Start with the free trial and assess the results before subscribing, with no automatic charges.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
