Darwin Region - Rural Roads - Bituminous Pavement Repairs for a Period of 36 Months - Bituminous repairs and minor rehabilitation of existing sealed roads and highways including but not limited to: - Pothole Patching - Edge Break Repairs - Regulation Patching - Reconstruction Patching - Spray Sealing - Minor reconstruction with surface works The contractor will be required to undertake pothole inspections on a number of higher use important roads - fortnightly in November and from April to May, and weekly
Bituminous pavement repairs and minor rehabilitation of existing sealed roads and highways Pothole patching, edge break repairs, regulation patching, reconstruction patching, spray sealing, minor reconstruction with surface works
AI helper
Contract covers bituminous repairs and minor rehabilitation of rural roads in the Darwin region for 36 months. Works include pothole patching, edge break repairs, and spray sealing. The contractor must use the Konect electronic management system for inspections and defect logging. Tender closing date is 22 September 2026. Indigenous Development Plan submission is required within 14 days of contract award.
Payment for scheduled work will be made at the tendered rate. payment for scheduled work will be made at the tendered rate.
The contractor must provide warranties for workmanship and manufacturers and/or suppliers warranties for products used in the works, in the name of the principal. provide warranties for workmanship and manufacturers and/or suppliers warranties for products used in the works, in the name of the principal.
Tender responses will be shortlisted based on: completeness of response, local content, past performance, whether the tender response presents an acceptable level of risk to the principal and price. tender responses will be shortlisted based on: completeness of response, local content, past performance whether the tender response presents an acceptable level of risk to the principal and price.
A fully developed Indigenous Development Plan will be required within fourteen 14 days of contract award. a fully developed plan will be required within fourteen 14 days of contract award.
Failure to meet service levels can result in adverse contractor performance scorecard notation, disputed invoices, or breach of contract notice. relevant invoices will be disputed if relevant, breach of contract notice may be issued to contractor for failure to meet overall contracted standard of delivery of works.
**** - Campbell Rd Stage 2 Reconstruction SLK 0. 45- 1. 05 - Please refer to the Request for Tender documentation and associated attachments
Road reconstruction and asphalt resurfacing Full reconstruction of Campbell Road between North Road and Cockburn Road, and asphalt resurfacing works from Cockburn Road to Middleton Road, Centennial Park.
AI helper
The City of Albany seeks a contractor for the full reconstruction of Campbell Road and asphalt resurfacing. The tender closes on November 16, 2026, at 10:00 am AWST. A mandatory site inspection is scheduled for November 3, 2026, at 8:30 am. The evaluation uses a best value for money approach. The contract period is 10 weeks, commencing February 1, 2027, with practical completion by April 9, 2027.
The tender closing date is November 16, 2026, at 10:00 am AWST. deadline: 10: 00am awst, monday 16th november 2026
The contract shall be completed at the end of the defects liability period twelve 12 months from the date of practical completion. The contract shall be completed at the end of the defects liability period twelve 12 months from the date of practical completion
The principal has adopted a best value for money approach to this request. The principal has adopted a best value for money approach to this request.
Attendance at the site inspection is mandatory on Tuesday, November 3, 2026, at 8:30 am. attendance at this meeting is mandatory.
Offers not submitted before the deadline or at the specified place may be rejected. an offer may be rejected without consideration of its merits in the event that: a it is not submitted before the deadline
RFT26- 019 College Avenue Reconstruction - The City' s objectives with this Request for Tender are to engage a suitably qualified and experienced Contractor to design, reconstruct and resurface a 1. 62 km section of College Avenue in Busselton. The existing pavement has asphalt surfacing with notable deterioration requiring a combination of reconstruction and resurfacing. This urban road supports high traffic volumes, and all works will be conducted at night to minimise disruption. A concept design, reconst
Road reconstruction and resurfacing Reconstruction and resurfacing of a 1. 62 km section of College Avenue in Busselton, including asphalt overlay, limestone basecourse, concrete infill, and path construction.
AI helper
The City of Busselton seeks a contractor to design, reconstruct, and resurface a 1. 62 km section of College Avenue. All works must be conducted at night to minimize disruption. A concept design, reconstruction methodology, and durable surfacing solution for a minimum 30-year design life are required. The tender opens on 11 September 2026 and closes on 14 October 2026.
**** - Stormwater Upgrades - Sunshine Coast Stadium North, Bokarina - Stage 1A - This project includes removal of the existing trunk line and installation of the new reinforced concrete box culverts and stormwater infrastructure, it will involve some disruption to businesses on Trade Lane and will require the contractor to manage Traffic and pedestrians in a live environment. There will be some access constraints due to Stadium events, and this will need to be built into the Contractors program. Works wi
Stormwater upgrades Removal of existing trunk line, installation of new reinforced concrete box culverts and stormwater infrastructure, dewatering, acid sulphate soil management, groundwater control, access chamber construction, lake kawana outlet works, reconstruction of revetment walls, trade lane reinstatement, sportsman parade reinstatement, sewer realignment and replacement, temporary relocation of the pontoon, site demobilisation and project completion documentation.
AI helper
This lump sum contract involves the removal of an existing trunk line and installation of new reinforced concrete box culverts and stormwater infrastructure at Sunshine Coast Stadium North, Bokarina Stage 1A. The contractor must manage traffic and pedestrians in a live environment, accounting for stadium event access constraints. Council will supply all RCBC culverts; the contractor supplies other materials, plant, and labour. The tender closes on 22 September 2026. Evaluation criteria include capability and experience (20%), methodology (40%), social and economic factors (20%), and price (20%).
The evaluation criteria and weightings are: capability and experience 20, methodology 40, social and economic factors 20, price 20.
Any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process.
**** - DRFA 2025 - Black Pinch Area Reconstruction - Refer to RFT documentation enclosed. - Refer to RFT documentation enclosed. Desired Outcomes (' Nice to haves', Conditions & Warranties, SLA' s, Project benefits) Details Refer to RFT documentation enclosed.
Landslide reconstruction works Site 6 adjacent to lot 157 cootharaba road, Site 7 adjacent to lot 266 black pinch road, Site 8 adjacent to lot 325 black pinch road, Site 9 adjacent to lot 325 black pinch road
AI helper
Noosa Shire Council invites tenders for reconstruction works of landslides on Blackpinch Road. The contract is a lump sum. Tenders must be submitted by 2:00pm AEST on 17 September 2026. A site inspection is scheduled for 2 September 2026, which is optional but strongly recommended. Evaluation criteria include price (35. 0%), experience and capability (25. 0%), methodology (25. 0%), health and safety (5. 0%), quality management systems (2. 5%), environment and sustainability (5. 0%), and contribution to local economy (2. 5%).
Evaluation criteria weighting price 35. 0%, experience and capability 25. 0%, methodology 25. 0%, health and safety 5. 0%, quality management systems 2. 5%, environment and sustainability 5. 0%, contribution to local economy 2. 5%.
A pretender briefing is scheduled to take place at the gate entrance to twin hills inspection, lookout, black pinch road, cootharaba commencing at 9:00 am on 2 September 2026. while the meeting is optional, attendance is strongly recommended.
Respondents must not canvass or otherwise communicate with any councillor or employee of noosa shire council in relation to this request for tender except as expressly provided in part 3 procurement process conditions.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I liked the way they search for tenders and provide us with the link to view them.
C. J. P. Perez
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
Excellent information. Just what I was looking for.
L. H. Borrelli
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
It encompasses all portals in one place.
G. Ferrea
A very good platform.
D. C. Espinosa
Simple, easy to use, and always up to date.
J. Z. Abi-zaid
It’s one of the best platforms for searching bids.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
