Road Tenders

Quotations are to be submitted by 3:00 PM AEST on Wednesday 15 July 2026. until 3. 00pm aest on wednesday 15 july 2026.

The award criteria include pricing schedule, previous similar experience, business references, methodology, program, third party accreditation, and work health and safety. criterion 1 pricing scheduleall items are to be priced including supply of all materials, equipment and labour, etc to complete the services, unless otherwise stated.

Consultants must be suitably qualified. quotations are invited from suitably qualified consultants for the above.

A pre-quotation briefing is scheduled for 12 noon on Thursday 2 July 2026 on site. Attendance is recommended but not mandatory. a pre- quotation briefing is scheduled for 12 noon on thursday 2 july 2026 on site. attendance is recommended but is not mandatory.

Late quotations will not be considered. late quotations will not be considered.

The closing date for this quotation tender is 20th July 2026 at 2 PM.

Payment will be made within 30 days of receiving a valid tax invoice, provided satisfactory evidence of completed works is received. The contractor will be paid by TSIRC within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.

A defect liability period of 12 months from the completion date is required. The contractor must, at no additional cost, remedy any defect in the works within 30 days of being notified by TSIRC.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. The quoted price and relevant non-price criteria will be assessed together to determine the most advantageous outcome for the principal.

Respondents must provide an overview of their experience and past performance in projects of similar nature, scope, and size, as well as details of the experienced personnel involved. Provide an overview of contractors experience and past performance in projects of similar nature, scope and size.

If works are not completed within the requested timeframe, TSIRC nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. If works are not completed within the requested timeframe, TSIRC nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.

Attendance at site inspection is listed as 'na' (not applicable).

Supplier query cutoff is Friday 17 July 2026 at 01:00 AM E. South America Standard Time.

The RFQ will be classed as non-conforming if the line breakdowns for the lump sum price breakdown schedule have been amended, or if the quotation form and response schedules are not completed. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming