The Town of Port Hedland is seeking a contractor to demolish and dispose of two existing ablution blocks and install two new double universally accessible toilet (UAT) modular ablution blocks at Cemetery Beach. Submissions are due by Friday, 26 June 2026, 2:00 PM AWST. A non-mandatory site inspection is scheduled for Tuesday, 09 June 2026, at 10:00 AM AWST. All questions must be submitted online via VendorPanel. The contract will be awarded based on a best value for money approach, considering price, qualitative criteria, and compliance. The project involves demolition, site preparation, supply and installation of modular blocks, and service connections. The contractor is responsible for design development, obtaining statutory approvals, and managing all aspects of the construction works, including safety and environmental protection. A fixed price contract is required, and all prices must include GST. The defect liability period is 12 months.
The deadline for submissions is Friday, 26 June 2026, at 2:00 PM AWST.
Progress claims are to be submitted by the 3rd day of the month for works completed in the month prior. The basis for this contract will be fixed price.
The defect liability period is 12 months from the date of practical completion. The contractor will also be required to provide operation and maintenance manuals, including warranty periods for supplied assets.
The contract may be awarded to a single respondent who best demonstrates the ability to provide quality products and/or services at a competitive price, using a best value for money approach.
The Town is seeking a suitably qualified contractor. Respondents must demonstrate relevant experience, capacity to deliver, and a demonstrated understanding of the methodology.
Liquidated damages for late completion are set at $105 per day.
A non-mandatory site inspection will be held on Tuesday, 09 June 2026, at 10:00 AM AWST at Cemetery Beach Park East Ablutions.
Supplier query cutoff is Wednesday, 24 June 2026, 03:00 AM E. South America Standard Time.
Submissions received after the deadline, not submitted at the specified place, or incomplete may be rejected. Tenders found to contain viruses may be excluded.