Interior Design Tenders

The principal's requirement is for separable portion 1 and separable portion 2 to achieve practical completion by 30 June 2027. the principals requirement is for separable portion 1 and separable portion 2 to achieve practical completion by 30 june 2027

Progress claims are due on the 21st day of each month for work done to that date. times for progress claims 21st day of each month in which wuc is carried out up to and including the month in which practical completion is reached

The contractor warrants that all plant, equipment, materials, parts, consumables or other goods supplied shall be new, free from defects and of merchantable quality. be free from defects and of merchantable quality

Tenderers must demonstrate experience in design and construct building projects, refurbishment of occupied facilities, roof replacement works and public building extensions. tenderers must demonstrate experience in design and construct building projects, refurbishment of occupied facilities, roof replacement works and public building extensions

Liquidated damages are set at $1,000 per day for each separable portion. liquidated damages, rate subclause 34. 7 **** per day

A mandatory site inspection will be conducted as detailed within the tender documentation. a mandatory site inspection will be conducted as detailed within the tender documentation

Engaging in improper conduct, including collusive tendering or failing to declare a conflict of interest, is prohibited. engaging in any collusive tendering, anticompetitive conduct, or any other unlawful or unethical conduct

Submissions must be received by 2:00pm on Wednesday, 11 November 2026. The document states: submit your registration of interest by 2. 00pm on wednesday, 11 november 2026.

Artists must demonstrate connection to the health service, relevant experience, and availability. The document states: artists and collectives with a demonstrable connection to the pah are welcome to register their interest.

Applicants must provide up to five images of past artworks. The document states: provide up to five (5) highquality images of past artworks that may be of interest to this project.

Late or incomplete submissions may not be considered. The document states: late or incomplete submissions may not be considered.

A minimum warranty period of 5 years is required on all parts and components for workstations and loose furniture, as stated: A minimum warranty period of 5 years is required on all parts and components.

Payment claims are made progressively, with the principal paying the scheduled amount within 15 business days after receiving the claim. The contract states: the principal must pay the contractor the scheduled amount if any by the date that is 15 business days after the principals representatives receipt of the relevant payment claim.

The contractor warrants that all materials and equipment supplied will be new, fit for purpose, and comply with the National Construction Code. The contract states: all material and equipment it supplies under this contract will be new unless the principal agrees otherwise in writing, fit for purpose and comply with the national construction code.

The contractor must be appropriately qualified and experienced. The contract states: seeking submissions from appropriately qualified and experienced respondents for the design and construction of the refurbishment works.

Liquidated damages of $100 per day apply for late completion. The contract states: liquidated damages will be due and payable to the principal by the contractor at the rate stated in item 17 which is $100 per day.

Failure to provide security within 3 business days after the contract date may result in default. The contract states: the contractor must, within 3 business days after the contract date, provide such guarantees to the principals representative.