Bench Tenders

Offers must be lodged by 10:00am AWST on Wednesday 25 November 2026. The deadline for this request is 10: 00am awst wednesday 25november 2026.

The principal has adopted a best value for money approach. the offer containing the lowest price will not necessarily beaccepted.

Liquidated damages of $500 per day apply if work does not reach practical completion by the specified date. liquidated damages of 500 per day will apply.

There is a tender briefing/site inspection available to inspect concrete forms at the city depot. attendance at this meeting is not mandatory.

Offers that do not contain all information requested as per selection criteria will be excluded from evaluation. offers that do not contain all information requested as per selection criteria will be excluded from evaluation.

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome for the principal.

All work must be carried out by experienced and licensed personnel in the field of work specified.

if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming

Quotations must be lodged by 29th October 2026 @2pm. The close date is stated as close date: 29th october 2026 @2pm.

Payment is made within 30 days of receiving a valid tax invoice. The text states: the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice.

The contractor warrants the works will be free from defects, comply with standards, and be fit for purpose. The text states: be free from any charge, liability or defect comply with all applicable standards be fit for purpose.

The award is based on best value for money. The text states: awarded to the respondent who best demonstrates the ability to provide best value for money.

Contractors must be experienced and licensed in their field. The text states: All work must be carried out by experienced and licensed personnel in the field of work specified.

If works are not completed within the requested timeframe, the work order may be removed. The text states: tsirc nominated representatives have the authority to remove the system work order from the contractor.

If the quotation form and response schedules are not completed, the RFQ will be non-conforming. The text states: if the quotation form and response schedules are not completed the rfq will be classed as non- conforming.

Offers must be submitted electronically through VendorPanel or by email, no later than 2:00 p. m. AEST on 06 November 2026. the latest time by which a submission must be logged.

Tenderers may undertake a self-guided site inspection if desired. tenderers wishing to attend the site are requested to email ***@***. *. *

Late submissions may not be accepted. late submissions may not be accepted.