The engagement will be awarded to the respondent who best demonstrates the ability to provide best value for money. The contractor must complete the quotation form and response schedules. The lump sum price breakdown must be fully completed. The contractor is responsible for ensuring minimal disruption to tenants and may need to provide temporary facilities if services are unavailable. The contract is subject to referenced documents including QBuild general terms and conditions.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.
If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.
