Commissioning Tenders

A non-mandatory site briefing is available for respondents to review the existing site infrastructure. a nonmandatory site briefing is available for respondents to review the existing site infrastructure

Completion of all works, including commissioning, is required by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site or materials delivered to site. progress claims may be submitted for works fully executed on site. . . or for materials procured and delivered to site ready for use.

12 months warranty on all workmanship from practical completion. the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Works shall be undertaken by a suitably qualified, experienced and appropriately licensed electrical contractor. the works shall be undertaken by a suitably qualified, experienced and appropriately licensed electrical contractor.

Failure to maintain progress may result in liquidated damages. failure to maintain progress. . . may constitute a breach of the contract and may result in the application of liquidated damages.

No mandatory site visit, but requests are welcome. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Direct contact with council employees, councillors, or consultants is strictly prohibited and will result in automatic disqualification. any breach of this protocol. . . will result in automatic disqualification from the contracting process.

Completion of all works including commissioning is required by 17 December 2027. The document states: completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site or materials delivered to site. The document states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation.

The contractor provides 12 months warranty on all workmanship from practical completion. The document states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Submissions assessed on tendered prices, past performance, methodology, WHS systems, availability, and local content. The document states: tendered prices, past performance experience of contractor and project team, suitability of methodology in the delivery of the works.

Contractor must be suitably qualified, experienced, and appropriately licensed. The document states: the works shall be undertaken by a suitably qualified, experienced and appropriately licensed electrical contractor.

Liquidated damages may apply for failure to maintain progress. The document states: failure to maintain progress in accordance with the approved project schedule. . . may result in the application of liquidated damages.

No mandatory site visit, but requests are welcome during the tender period. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Direct contact with council employees or councillors outside Vendor Panel results in automatic disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification.