Bathroom Renovation Tenders

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants the works will be free from defects and fit for purpose. the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose

Best value for money, assessing price and non-price criteria. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome

All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified

RFQ non-conforming if schedules incomplete or amended. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants the works will be free from defects and comply with standards. the contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect

Best value for money, assessing quoted price and non-price criteria. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome

All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified

RFQ will be non-conforming if schedules are not completed. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming

Quotation must be lodged by 18 November 2026 at 2pm. The close date is stated as close date: 18th november 2026 @2pm.

Payment is lump sum on completion with progress claims considered upon request. Contractor paid within 30 days of receiving a valid tax invoice.

Defect liability period is 12 months from completion date. Contractor must remedy defects within 30 days of being notified by tsirc at no additional cost.

Award based on best value for money with weightings: local content spend and employment 15 tender price and commercial terms 45 quality, reliability and historical performance 15 occupational health and safety swms 10 ability to commence complete on schedule 15.

All work must be carried out by experienced and licensed personnel in the field of work specified. Contractors must hold appropriate insurances including public liability insurance of $20,000,000.

If works not completed within requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.

RFQ will be classed as non-conforming if the lump sum price breakdown schedule is amended or if quotation form and response schedules are not completed.

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome for the principal.

All work must be carried out by experienced and licensed personnel in the field of work specified.

if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming