Tennant Creek Region - Sandover Highway - Flood Damage Repairs at Various Locations - The works to be undertaken comprise of repairs to the Sandover Highway in the Barkly Region. Subgrade preparation by rip and recompact method using existing surface and batter material to form road carriage way. Followed by gravel resheet over the constructed subgrade pavement works including. sourcing, extraction, processing by way of blending or screening and import of compliant gravel materials; extr
Tender for Sandover Highway Flood Damage Repairs at Various Locations null
AI helper
The tender is for flood damage repairs on the Sandover Highway. The closing date for the tender is January 19, 2026, at 2:00 PM Australian Central Standard Time. The tender requires the completion of separate tender response schedules. The Northern Territory Government Conditions of Tendering apply. Tenderers must inform themselves of all circumstances and conditions relating to submitting a tender response and carrying out the works. An Indigenous Development Plan is required within fourteen days of contract award. The tender also requires a project control plan. The assessment criteria include price, past performance, local content, timeliness, and capacity. The tender responses must remain valid for 90 days. The tenderer must be accredited or recognized by Contractor Accreditation Limited (CAL).
The bid notice states he time for practical completion of the works shall be: clause 54. 2and, for each separable part of the works: as nominated by the tenderernot applicable
The bid notice states selection of the successful tenderer will be based on a best value for territory assessment of tender responses against the tender assessment criteria specified in this clause 1. 21.
The bid notice states he tenderer is required, at the time and date for closing of the rft, to be accredited or recognised by contractor accreditation limited cal.
The bid notice states liquidated damages for the works shall beclause 54. 5 30, **** per weekfor each separable part of the works shall be: not applicable
Tennant Creek Region - Kurundi Road - Reformation and Gravel Resheet 81km - 101km - A general outline of the work to be carried out under the Contract comprises: Subgrade preparation by rip and recompact method using existing surface and batter material to form road carriage way. Followed by gravel resheet over the constructed subgrade pavement works including. sourcing, extraction, processing by way of blending or screening and import of compliant gravel materials; extraction and import
Tennant Creek Region Kurundi Road Reformation and Gravel Resheet 81km - 101km
AI helper
The tender is for the reformation and gravel resheeting of Kurundi Road. The conditions of tendering and contract are provided separately. The project requires an Indigenous Development Plan within 14 days of contract award. A project control plan must be submitted within 14 days of contract award. The assessment criteria include price, past performance, local content, and timeliness. The time for commencement is 14 days and the time for completion is 16 weeks. The contractor must adhere to environmental management standards and provide necessary permits. The contractor must also provide a project control plan and adhere to hold and witness points. The contractor must also provide a project control plan and adhere to hold and witness points.
The time for completion is 16 weeks, as stated in the conditions of contract.
The defects liability period is 52 weeks, as stated in the conditions of contract.
Tender responses will be shortlisted based on completeness of response, local content, past performance, whether the tender response presents an acceptable level of risk to the principal and price, as stated in the conditions of tendering.
There is no industry briefing, as stated in the annexure to the conditions of tendering.
Tennant Creek Region - Ranken Road - Reformation and Gravel Resheet 91km - 102km - A general outline of the work to be carried out under the Contract comprises: Subgrade preparation by rip and recompact method using existing surface and batter material to form road carriage way, as per drawing CS- **** by gravel resheet over the constructed subgrade pavement works including: - Sourcing, extraction, processing by way of blending or screening and import of compliant gravel materials - Extraction a
Tennant Creek Region Ranken Road Reformation and Gravel Resheet 91km - 102km
AI helper
The tender is for the reformation and gravel resheeting of Ranken Road. The closing date is November 3, 2025, at 2:00 PM Australian Central Standard Time. The tender response schedules must be completed. The conditions of tendering and contract are provided separately. An Indigenous Development Plan is required within 14 days of contract award. A project control plan must be submitted within 14 days of the contract being awarded. The time for commencement is 14 days, and the time for completion is 10 weeks. The contractor must provide a declaration from the subcontractor confirming payment of the subcontractors previous tax invoice with supporting evidence or detailing the status of the dispute relating to the subcontractors previous tax invoice if it is unpaid.
The time for completion is 10 weeks.
The defects liability period is 52 weeks.
Tender responses will be shortlisted based on completeness of response, local content, past performance, whether the tender response presents an acceptable level of risk to the principal and price.
Leadership Development Program - Leadership Development Program- The Leadership Development Program opportunity is to partner with the RBA to design and deliver a flagship, multi- level program aligned with six endorsed leadership expectations, supporting the Bank s transformation and cultural ambition to be open and dynamic. This initiative will begin with one pilot program each for business executive, senior leaders, and mid- level leaders, with the goal of scaling across the Bank over 2- 3 years using mo
Leadership development program
AI helper
The Reserve Bank of Australia (RBA) is seeking proposals for a leadership development program. The initial pilot program is anticipated to commence in February 2026, and the full program is expected to run for 23 years. Proposals must be submitted electronically via Austender by 2:00 PM Sydney time on 2 September 2025. The program will involve designing and delivering a multilevel leadership development program aligned with six endorsed leadership expectations. The successful respondent will be required to work with the bank to design and conduct a series of learning experiences for each leadership cohort. The contract term is initially anticipated to be approximately 12 months to deliver the pilots, with a further term of 24 months possible if the pilots are deemed successful. The pricing model will include an initial charge for content development and pilot programs, followed by a separate charge for each subsequently delivered program, separated by cohorts. The total pricing for delivery should be based on all programs and cohorts over the entire contract term.
The closing time for proposals is 2:00 PM Sydney time on 2 September 2025.
The evaluation criteria include respondent profile, capacity and capability, fit with requirements, quality and compliance, corporate social responsibility and sustainability, and pricing.
The respondent must exist as a legal entity at the closing time, not be subject to a judicial decision against them relating to employee entitlements (not including decisions under appeal), and have not paid the claim. If a relevant employer, the respondent must be compliant with its obligations under the Workplace Gender Equality Act **** (Cth). The respondent is not precluded from tendering for Australian government funded work at closing time.
Progress Project Name: **** Phase 6 AEGIS Training On- shoring RFI - **** Ph6 AEGIS Training On- Shoring- Deliver AEGIS training courses, as well as maintain AEGIS training systems and simulators, and will be part of a blended APS/ADF/Contractor team at Navy Training Systems Centre - Randwick ( NTSC- R) and HMAS Watson. The workforce may also be required to maintain communications with Maritime Integrated Warfare Systems ( MIWS) to ensure currency of systems and training material
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Start your free trial and receive email alerts
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/territories, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits Australia (975 real users, 10/12/2025).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
It is complete and optimal, it improves my time.
R. de L. Cruz
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
It’s easy to stay connected to tenders across multiple municipalities at the same time. Tenders are easy to view.
A. P. e S. L. Epp
I’m notified immediately about every tender that opens in my area. It really helps my work.
E. Goncalves
The email alert is amazing. I really liked the speed — the bid notices arrive by keywords directly in my inbox, which makes searching much easier. I only need to focus on the other processes, which is a big relief.
We selected the most helpful reviews from real users. Order may change periodically.
Easy to find the bids.
R. M. David
A complete, easy-to-use system. Support from calm, patient, and clear-teaching professionals.
W. M. Da Silva
With the chosen keywords, I can find many tenders of interest! I learn about new notices well in advance, giving me enough time to get organized to participate.
D. Comaq
Very good — I find exactly what I’m looking for. It’s a great experience.
G. Sigrist
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
I’ve used another platform before, and after discovering this one, I can see it’s much better. I find my tender opportunities faster, which speeds up my work.
A. de F. Araujo
Practicality, speed, trust, and credibility—that’s what the work conveys. The information is precise and sharply targeted.
N. De Lima
Your search service has helped me a lot, improving the results of our contracts.
R. Lima
Information arrives continuously—filtered and easy to understand.
A. Benedito
Very fast. Finds tenders quickly.
C. Jose
I’m satisfied with the service.
E. Dos Santos
The platform searches for processes even on city hall websites, and it’s very intuitive and easy to use.
BidHits Australia is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals every day at the Commonwealth, state/territory and local council levels. Tenders are added to the system as soon as they are published on the source portal.
Plans start at A$ 59.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia. Start by adding a few keywords. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits Australia now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 975 active users, conducted through 10/12/2025.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
