****- 25 Hamilton Road Upgrade and Landscaping - The Town is seeking a suitability qualified Contractor to deliver the construction of the Hamilton Road upgrade and associated landscaping. The Hamilton Road upgrade includes the construction of two round- abouts and the required road realignment to connect with the new round- abouts. This upgrade is designed to improve safety and facilitate the seamless movement of vehicles and reduce traffic congestion during peak times. These round- abouts and road upgr
Construction of Hamilton Road upgrade and associated landscaping, including two roundabouts and road realignment. Hamilton Road upgrade, landscaping, irrigation infrastructure installation, streetlight relocation enabling works.
AI helper
Contractor sought for Hamilton Road upgrade and landscaping in Port Hedland, WA. Project includes two roundabouts, road realignment, landscaping, and irrigation. Key considerations include managing numerous underground services, maintaining 24/7 traffic access, and adhering to strict safety and environmental regulations. Mandatory site inspection and preliminary visit required. Tender closes July 3, 2026.
Practical completion is targeted for 28 June 2027.
Progress claims are to be submitted by the 3rd day of the month for works completed in the month prior.
A 12-month defects liability period applies from the date of practical completion.
The town is seeking a suitability qualified contractor.
Liquidated damages are set at **** per day for late completion.
A mandatory site inspection is scheduled for 21 and 27 May 2026.
Supplier query cutoff is Tuesday 30 June 2026 03:00 am.
An assessment of o against any mandatory criterion will eliminate the submission from consideration.
**** Streetscape Upgrade - Mill and Currie Streets, Nambour - Sunshine Coast Council is seeking a suitably qualified contractor to construct streetscaping, roadworks and a signalised crossing at, and adjacent to the intersection of Mill and Currie Streets, Nambour. The scope of work includes, but is not limited to: Signalised pedestrian crossing Lighting Road pavement works Concrete pavement construction; Paved pathway construction; Landscaped gardens; Concrete driveways and kerb ramps; Signage and line
Streetscape upgrade, roadworks, and signalised crossing construction Signalised pedestrian crossing, lighting, road pavement works, concrete pavement construction, paved pathway construction, landscaped gardens, concrete driveways and kerb ramps, signage and line marking, kerb channel works, stormwater drainage works, supply and installation of precast islands, public utility alterations, traffic and pedestrian management, site management, environmental management, WHS management, subcontractor management, maintenance and defects rectification.
AI helper
Sunshine Coast Council is seeking a contractor for streetscaping, roadworks, and a signalised crossing in Nambour. The scope includes various construction elements like paving, landscaping, drainage, and utility alterations. Contractors require TMR prequalification R2 B1 F5. A site visit is not scheduled; respondents must conduct their own due diligence. The contract is a lump sum. Tenders close 12 noon on 26 May 2026. Evaluation criteria include capability, experience, methodology, social/economic factors, and price. All submissions must be electronic via VendorPanel.
Tenders will be accepted until 12 noon on 26 May 2026.
Tenders will be evaluated against capability and experience (20%), methodology (25%), social and economic factors (20%), and price (35%).
Contractors are required to hold a minimum TMR prequalification of R2 B1 F5.
A site information session will not be held for this tender. Respondents are to carry out their own due diligence in relation to familiarising with the site.
Clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
Direct contact with any elected member of council or local government employee regarding any part of this tender, other than those listed in schedule 1 item 5, is prohibited. Any prohibited contact may result in disqualification.
**** Streetscape Upgrade - Mill and Currie Streets, Nambour - Sunshine Coast Council is seeking a suitably qualified contractor to construct streetscaping, roadworks and a signalised crossing at, and adjacent to the intersection of Mill and Currie Streets, Nambour. The scope of work includes, but is not limited to: Signalised pedestrian crossing Lighting Road pavement works Concrete pavement construction; Paved pathway construction; Landscaped gardens; Concrete driveways and kerb ramps; Signage and line
Streetscape upgrade, roadworks, and signalised crossing construction Signalised pedestrian crossing, lighting, road pavement works, concrete pavement construction, paved pathway construction, landscaped gardens, concrete driveways and kerb ramps, signage and line marking, kerb channel works, stormwater drainage works, supply and installation of precast islands, public utility alterations, traffic and pedestrian management, site management, environmental management, WHS management, subcontractor management, maintenance and defects rectification.
AI helper
Sunshine Coast Council is seeking a contractor for streetscape upgrades, roadworks, and a signalised crossing at Mill and Currie Streets, Nambour. The scope includes various construction and management tasks. Contractors require a minimum TMR prequalification of R2 B1 F5. A site information session will not be held; respondents must conduct their own due diligence. This is a lump sum contract. Tenders close at 12 noon on 26 May 2026. Evaluation is based on mandatory criteria, non-price criteria (capability, experience, methodology, social/economic factors), and price.
Tenders will be accepted until 12 noon on 26 May 2026. his document represents the release of the tender to the markettenders will be accepted until 12noon 26 may 2026
Tenders will be evaluated against mandatory criteria, non-price criteria (capability and experience, methodology, social and economic factors), and price. enders will be evaluated against the below prescribed evaluation criteria, using a multistage evaluationprocess, outlined below:. stage 1 mandatory criteria0 stage 2 nonprice criteria0 stage 3 price.
Contractors are required to hold a minimum TMR prequalification of R2 B1 F5. for this project contractors are required to hold a minimum tmr prequalification of r2 b1 f5.
A site information session will not be held. Respondents are to carry out their own due diligence. a site information session will not be held for this tender. respondents are to carry out their own duediligence in relation to familiarising with the site.
Clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date. clarifications cutoff for requests for clarification or further information will not be acceptedclause 3. 10 of the pt on or after the date that is 3 business days prior to the closing date.
Direct contact with elected members or employees, other than the designated contact point, may result in disqualification. any prohibited contact with a local government employee or elected member of council may result inthe respondent or prospective respondent and their tender being disqualified from the tenderprocess.
****- 25 Hamilton Road Upgrade and Landscaping - The Town is seeking a suitability qualified Contractor to deliver the construction of the Hamilton Road upgrade and associated landscaping. The Hamilton Road upgrade includes the construction of two round- abouts and the required road realignment to connect with the new round- abouts. This upgrade is designed to improve safety and facilitate the seamless movement of vehicles and reduce traffic congestion during peak times. These round- abouts and road upgr
Construction of Hamilton Road upgrade and associated landscaping, including two roundabouts and road realignment.
AI helper
The Town of Port Hedland is seeking a qualified contractor for the Hamilton Road upgrade and landscaping project. This includes constructing two roundabouts and realigning the road to improve safety and traffic flow. The project involves significant underground services, requiring careful management. Landscaping and irrigation infrastructure will be installed, and existing streetlights will be relocated by a separate provider. All works must maintain 24/7 access to Hamilton Road, a critical thoroughfare. The contract duration is until practical completion on June 28, 2027. Tender submissions are due by July 3, 2026.
Practical completion is scheduled for 28 June 2027.
Progress claims are to be submitted by the 3rd day of the month for works completed in the month prior.
A defects liability period of 12 months from the date of practical completion is specified.
The evaluation will consider value for money, which includes offered price and pricing requirements.
Tenderers must be suitably qualified and demonstrate relevant experience, key personnel skills, understanding of methodology, and capacity to deliver resources.
Liquidated damages are set at **** per day based on potential losses associated with late completion.
A mandatory site inspection is scheduled for 21 and 27 May 2026.
An assessment of 'no' against any mandatory criterion will eliminate the submission from consideration.
RFQ2026/39 Traffic Management - Cootamundra- Gundagai Regional Council is seeking quotations from suitably qualified contractors and suppliers to provide services or materials for Traffic Management, further detailed within.
Traffic Management Services and Materials Crew vehicle, escort vehicle driver, trailer mounted traffic lights, portable traffic light, variable message board, arrow board, light tower, signage hire, traffic guidance scheme, road occupancy licence, traffic management plan, minimum charge, travel per 30minutes, away work accommodation, away work meals, stand down rate, emergency call out, meal allowance, normal time, time half, night shift, double time, public holiday.
AI helper
Cootamundra-Gundagai Regional Council is seeking quotations for traffic management services and materials. The tender closes on Friday, 12 June 2026, at 04:00 AM. A supplier query cutoff is on Wednesday, 10 June 2026, at 04:00 AM. The buyer's personal and contact details are hidden. The services include various traffic control elements like crew vehicles, escort drivers, traffic lights, signage, and traffic management plans.
The closing date for submissions is Friday, 12 June 2026, 04:00 am E. South America Standard Time.
Suppliers must be suitably qualified contractors and suppliers.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
90% recommend BidHits Australia (1061 real users, 16/06/2026).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
We selected helpful reviews from real users. Order may change periodically.
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
It encompasses all portals in one place.
G. Ferrea
It gives me information on tenders that interest me. It's easy to find tenders.
A. Armenta
It’s one of the best platforms for searching bids.
M. R. De Lima
The platform is very user-friendly.
N. Lobato
Excellent information. Just what I was looking for.
L. H. Borrelli
A complete, easy-to-use system. Support from calm, patient, and clear-teaching professionals.
W. M. Da Silva
Excellent platform to help promote and expand the reach of your work.
C. Merino
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
The system is very practical. It’s helped increase my monthly revenue.
F. H. Silva
It’s easy to stay connected to tenders across multiple municipalities at the same time. Tenders are easy to view.
A. P. e S. L. Epp
The search engine that finds what I'm looking for just by entering keywords
BidHits Australia helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00/month. All plans include the same features, and longer terms reduce the pro-rata cost. You can start with the free trial with no auto-charge.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits Australia shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits Australia now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1061 active users, conducted through 16/06/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
