Supply & Delivery of one Light Commercial Space Extra Cab 4x4 Tray Utility - Supply and Delivery of One Light Commercial Space Extra Cab 4x4 Tray Utility
Supply and delivery of one light commercial space extra cab 4x4 tray utility One light commercial space extra cab 4x4 tray utility, including diesel engine, automatic transmission, white colour, ABS brakes, steel wheels with all- terrain tyres, heavy duty suspension, cabin airconditioning, cruise control, reversing camera, UHF radio, bull bar, driving lights, long range fuel tank, tray with drop sides, toolboxes, tow coupling, electric brake controller, and other specified accessories
AI helper
Wentworth Shire Council seeks tenders for supply and delivery of one light commercial space extra cab 4x4 tray utility. Delivery required within 6 weeks from receipt of purchase order to WSC depot in Wentworth, between 9am and 3pm. Payment under lump sum contract, fixed, only after successful handover. Warranty details, manuals, spare parts, and training to be provided. Evaluation criteria include cost (40%), fit for purpose (25%), fleet standardisation (10%), local serviceability (10%), and previous delivery performance (15%). Tenders must be lodged electronically via Vendor Panel platform by 5pm Wednesday 4 November 2026. Tender must remain open for 60 days.
Delivery must occur within 6 weeks from receipt of WSC purchase order. The document states: delivery of this item is to occur: 6 weeks from receipt of wsc purchase order or as agreed.
Payment is made under a lump sum contract, fixed and not subject to rise and fall. The document states: payment will only be made following successful handover of plant item.
The supplier must advise on the extent and nature of the warranty. The document states: the supplier shall advise of the extent and nature of the warranty on the unit and whether these are given andor honoured by the supplier or the manufacturer.
Evaluation criteria include cost (40%), fit for purpose (25%), fleet standardisation (10%), local serviceability (10%), and previous delivery performance (15%). The document states: supplier cost comparable and within budget: 40 fit for purpose: 25 fleet standardisation: 10 local serviceability: 10 previous delivery performance: 15.
Suppliers must provide company information, financial referees, and details of experience. The document states: please provide 3 financial referees e. g. suppliers, wholesalers etc and how many years has the supplier been in business as a supplier of similar equipment.
Tenders that are incomplete, electronically corrupted, late, or verbal will not be considered. The document states: a tender that cannot be evaluated because it is incomplete or electronically corrupted may be passed over. late or verbal tenders will not be considered.
Supply and Install of 14 kVA Standby Generator at DUA SES - The Contractor shall supply, install, connect, test and commission a new 14 kVA standby generator, complete with a suitably rated Automatic Transfer Switch ( ATS) and all associated electrical and ancillary works required to provide a complete, compliant and fully operational automatic standby power system. The works shall be submitted as per a fixed lump sum The Contract shall be undertaken on a Fixed Lump Sum basis, with the Contractor agreeing t
AI helper
Fixed lump sum contract for supply, install, connect, test and commission a 14 kVA standby generator with ATS at Duaringa SES shed, 19 Mary Street, Duaringa QLD **** completion by end of December 2026. Tender closes 11 November 2026. Supplier queries cutoff 9 November 2026. Contract includes all labour, materials, plant, equipment, supervision, overheads and profit.
Projected to be completed by end of December 2026. The contract specifies a completion date in schedule 1, with liquidated damages for late completion. projected to be completed by end of december 2026
Payment is made against payment claims submitted by the contractor, with council issuing a payment schedule and paying within the timeframe stated in schedule 1. council will pay the amount in the payment schedule within the time frame stated in schedule 1
The contractor warrants goods will be new, of merchantable quality, free from defects, and manufacturer warranties must be provided to council. the contractor warrants that any goods supplied will: be new. . . be free from defects
The contractor must have necessary experience, appropriately qualified and trained workforce, and all required accreditations and licences. it has and will maintain the necessary experience, and an appropriately qualified and trained workforce
Liquidated damages apply at the rate stated in schedule 1 for each day completion is delayed beyond the completion date or key supply date. the contractor will be liable to council for liquidated damages at the rate stated in schedule 1
Failure to achieve completion by the completion date results in liability for liquidated damages. if the contractor fails to achieve completion by the completion date. . . the contractor will be liable to council for liquidated damages
The Hub Fire Compliance Services Upgrade - Livingstone Shire Council invites tenders from suitably qualified and licensed contractors for Tender **** - The Hub Fire Compliance Services Upgrade. The project comprises upgrades to the fire detection and alarm systems at The Hub, which accommodates commercial tenancies on the ground floor and offices on Levels 1 and 2, together with associated improvements to the ground- floor foyer entry. The works comprise the detailed design, supply, installation, conne
Upgrades to the fire detection and alarm systems at The Hub, including associated improvements to the ground- floor foyer entry Detailed design, supply, installation, connection, testing and commissioning of a complete fire detection and alarm system, associated electrical works and monitoring connections, replacement of ground- floor foyer entry doors with an automatic sliding door integrated with the new fire panel and existing access control system, associated building modifications, making good and certification
AI helper
Tenders due 12 November 2026 at 2:00pm via VendorPanel. Project involves detailed design, supply, installation, testing and commissioning of fire detection and alarm system at The Hub, Yeppoon, including automatic sliding door replacement. Site inspection strongly recommended on 3 November 2026, must register by email by 30 October 2026. Lump sum contract, 90-day tender validity. Evaluation criteria include price (30%), corporate capacity (20%), experience (15%), programming (25%), local content (10%). Licenses required for building, fire protection and electrical work.
The evaluation criteria include price with a weight of 30%, corporate and financial capacity 20%, previous experience 15%, construction programming methodology 25%, and local content 10%. As stated: criteria: price weight: ****
Tenderers must hold all required licenses including building work, fire protection work and electrical work. As stated: the tenderer must hold all licences, registrations, permits and authorisations required by applicable legislative requirements
A single joint site inspection will be held on Tuesday, 3 November 2026, meeting at the front of The Hub, 79 James Street, Yeppoon QLD **** stated: a single joint site inspection will be held at tuesday, 03 november 2026
Tenders not received by the closing time will not be considered. As stated: any submission not received before the specified closing time shall not be considered unless there is evidence satisfactory to council that a submission was sent prior to the closing time.
**** Low to Mid- Range Dual Cab 4x4 with Standard Tub - Cootamundra- Gundagai Regional Council is seeking quotations for the supply and delivery of a Low to Mid- Range Dual Cab 4x4 with Standard Tub as described in the attached specification.
Supply and delivery of a low to mid- range dual cab 4x4 with standard tub Dual cab 4x4 ute, V6 diesel, automatic transmission, **** braked towing capacity, 17- inch alloy wheels, white colour, tow kit with electric brakes, window tinting, rubber mats, tub with soft cover, bull bar, driving lights, seat covers, tow bar, rear air bag suspension
AI helper
Supply and delivery of a low to mid-range dual cab 4x4 with standard tub to Cootamundra-Gundagai Regional Council depot at 176 Hovell Street, Cootamundra. Price includes delivery and first scheduled service. Vehicles must have 12 months NSW registration. Training on safe operating procedures required at delivery. Quotations must be lodged via Vendor Panel by 17 November 2026, 2pm NSW time. Evaluation based on best value for money considering price, operational costs, product quality, support, delivery timeframe, and WHS benefits.
Quotations must be lodged via Vendor Panel by 17 November 2026, 2pm NSW time. The RFQ states: rfq closing date: 17 november 2026 rfq closing time: 2pm nsw time.
Warranty details must be submitted with the response. The RFQ states: details of all warranties are to be submitted with response. all terms and conditions must be clearly stated.
Evaluation is based on best value for money. The RFQ states: council will seek to obtain best value for money in any purchasing activity.
Respondents must complete all relevant sections and sign the bid statement. The RFQ states: failure to sign statement below by authorised representative will render bid invalid.
Supplier query cutoff is Friday 13 November 2026. The website states: supplier query cutoff friday 13 november 2026 12: 00 am.
Failure to adhere to instructions may result in rejection. The RFQ states: failure to adhere to these instructions and terms and conditions may result in rejection of the bid.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
