Nirimba Fields_ Stage 7 Civil and Associated Works - Defence Housing Australia ( DHA) invites Tenders from qualified civil and landscape contractors to this Request for Tende- Defence Housing Australia ( DHA) invites Tenders from qualified civil and landscape contractors to this Request for Tender ( RFT) for the provision of civil construction to be carried out in accordance with these Conditions of Tender for Nirimba Fields Stage 7. Note to Tenderer: Defence Housing Australia ( DHA) is not required to c
Civil construction works for Nirimba Fields Stage 7 residential subdivision Civil works including clearing, earthworks, pavements, drainage, sewer, water, electrical, landscaping, and associated infrastructure; drainage channels and regional basins; stormwater infrastructure; parks
AI helper
Tenders for civil construction at Nirimba Fields Stage 7, Sydney NSW. Must be lodged electronically via AusTender by 19 Nov 2026 3:00pm ACT time. Principal contractor required for civil and landscape works. Mandatory WHS accreditation scheme compliance. Tender validity 6 months. Contract commencement anticipated April 2027. Estimated value AUD **** million. Site inspections non-mandatory by appointment. Questions due 28 Oct 2026.
Practical completion of stage 7a 7b is desired by November 2027. practical completion of stage 7a 7b is desired by november 2027.
The evaluation criteria include experience and performance (20%), competency and capability (15%), resourcing (15%), WHS (10%), and price (40%). price a tenderers have completed the lump sum breakdown in 40 accordance with the schedule
Tenderers must demonstrate experience in delivering high-quality civil and landscaping work. tenderers must demonstrate experience in delivering highquality civil and landscaping work.
Site inspections are non-mandatory and by appointment only. dha will be conducting nonmandatory siteinspection, by appointment only on assessment of the requests
Questions must be submitted by Wednesday 28 October 2026 3:00pm Canberra time. questions must be submitted to dha procurement at ***@***. *. * by canberra time wednesday 28 october 2026 3: 00pm.
Failure to provide a tendered price will render the tender invalid. failure to provide a tendered price will render the tender invalid.
The estimated value is from AUD 15,000,**** to 31,000,****. estimated value aud: from 15, 000, **** to 31, 000, ****
26/27- 58 Ballarat Connections - Trail Works Whitelaw Avenue - This project includes the construction of a shared path as part of the broader Ballarat Connections trail. The project provides a shared path link alongside Whitelaw Avenue between Doug Dean Reserve and Sutton Street. Links back into the adjacent footpath network and south into Doug Dean Reserve are is also included. The combined length of the proposed path connections is just over **** and includes five shared user raised pedestrian crossings
Construction of a shared path as part of the Ballarat Connections Trail along Whitelaw Avenue, including raised pedestrian crossings, lighting, drainage, carpark and landscape works. Shared path construction, kerb and channel, raised pedestrian crossings, solar lighting, minor roadworks, asphalt works, concrete footpath and kerb construction, carpark extension ( 10 new spaces), pram ramps, planted drainage swales, grated drainage channels, side entry pits modification, grated pit modification, new kerb and WSUD kerb inlets, driveway crossover, tree protection, landscape works, tree planting, post and rail fencing, vehicle barriers, bollards, directional signage, road signage, seating, 26 weeks landscape establishment and maintenance.
AI helper
Construction of a shared path link along Whitelaw Avenue between Doug Dean Reserve and Sutton Street, Ballarat. Works include shared path, kerb and channel, raised crossings, solar lighting, drainage swales, carpark extension, landscaping, and 26 weeks landscape establishment. Contract is fixed lump sum, with 52-week defects liability period. Security required: 2 x 2. 5% of contract sum. Liquidated damages: $150 per day. Practical completion by 01/05/2027 or 60 days from execution. Payment claims due 30th business day monthly, payment within 30 days. Public liability insurance minimum $20 million. Tender closes 22 October 2026.
Practical completion is due by 01/05/2027 or 60 days from the execution date, as stated: date for practical completion clause 1. 1: **** or 60 days from the execution date.
Payment claims are due on the 30th business day of each month, with payment within 30 days after the payment schedule or tax invoice, as stated: period for payment clause 20. 3: 30 days after: a the issue of the payment schedule or b receipt of a tax invoice.
Defects liability period is 52 weeks, as stated: defects liability period clauses 1. 1 and 18. 1: 52 weeks.
Contractor must be registered in the Rapid Global Amalgamated Councils of Victoria database, as stated: the contractor must be registered in the rapid global amalgamated councils of victoria database and must maintain the required level of certification.
Liquidated damages are $150 per day for late completion, as stated: rate of liquidated damages clause 17. 1: 150 per day.
Failure to provide security within 5 business days after execution date prevents payment claims, as stated: if the contractor fails to do so, the contractor will not have any entitlement to submit any claim for payment until the contractor provides such security.
ECU Campus Retail Services - - ECU is seeking innovative retail partners capable of providing a contemporary, customer- focused retail experience that supports the diverse needs of students, staff, alumni, and visitors. The University is interested in solutions that combine physical retail, digital channels, and value- added services to enhance convenience, accessibility, and the overall campus experience. The scope of services may include, but is not limited to: Operation of a campus retail outlet and asso
AI helper
ECU seeks innovative retail partners for campus retail services across multiple campuses. Scope includes retail outlet operation, branded merchandise, uniforms, stationery, food and beverage, online retail, and logistics. EOI is first stage of a two-stage process; shortlisted respondents invited to RFP. Responses close 16 Oct 2026 at 2:00 PM Perth time. All responses must be submitted via eProcure platform; late responses may not be considered.
Responses close on Friday, 16 October 2026 at 2:00 PM Perth time. responses closes fri, 16 oct 2026 at 2: 00pm perth, western australia
Respondents must demonstrate capability, relevant experience, proposed retail concept, operational model, and ability to deliver integrated retail services. respondents are invited to demonstrate their capability, relevant experience, proposed retail concept, operational model, and ability to deliver integrated retail services
Responses lodged by any other means will not be considered, and late responses may not be considered. responses lodged by any other means will not be considered. late responses may not be considered.
Hamilton Channels Flood Resilience Upgrade - Boulia Shire Council are looking for suitable contractors to carry out work to upgrade a 405m section of the Kennedy Developmental Road 99D between Winton and Boulia. This project is to improve the flood resilience at the Hamilton Channels.
Hamilton Channels Flood Resilience Upgrade - Boulia Shire Council are looking for suitable contractors to carry out work to upgrade a 405m section of the Kennedy Developmental Road 99D between Winton and Boulia. This project is to improve the flood resilience at the Hamilton Channels.
AI helper
Boulia Shire Council seeks contractors to upgrade a 405m section of Kennedy Developmental Road 99D to improve flood resilience at Hamilton Channels. Tenders must be submitted by 2:00 pm on September 18, 2026. Evaluation criteria weight price (50%), local content experience (40%), and quality of submission (10%).
Evaluation criteria weighting price 50 local content experience 40 quality of submission 10
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
