Motor Vehicle Cargo Terminal SP1 - The purpose of the project is to undertake the drainage, service- interface and security works required to improve the existing drainage corridor and secure the existing Benwell Road car park. These works also support the Port' s future development of additional motor vehicle and cargo storage capacity, which does not form part of this Contract. The recent construction of the Dedicated Laydown Area and the East Port Connection Road changed the available capacity and draina
Drainage, service interface, and security works Drainage corridor improvement, security works for Benwell Road car park, modification of drainage channel, erosion protection, service relocation/protection/installation, security fencing/gates/signage/bat deflectors, pavement marking/signage modification, landscaping/revegetation/erosion and sediment controls, temporary works.
AI helper
The project involves drainage, service interface, and security works to improve the existing drainage corridor and secure the Benwell Road car park. The tender requires submission of a conforming tender, which must comply with all conditions. A mandatory tender briefing/site inspection is scheduled for 15/09/2026. Offers must be lodged electronically by 29/09/2026 at 5:00pm EST. Evaluation criteria include mandatory criteria (insurance, modern slavery, Qld government code of conduct, previous performance) and qualitative criteria (local benefits, region/community benefits, capability, quality).
The criteria include mandatory criteria like insurance compliance, modern slavery compliance, qld governments code of conduct compliance, previous performance and/or referee reports verified and qualitative criteria like local benefits, including local workforces and use of local suppliers in the supply chain.
Tenderers must meet mandatory criteria including insurance compliance, modern slavery compliance, qld governments code of conduct compliance, previous performance and/or referee reports verified.
A tender briefing site inspection is scheduled for 1: 00pm, tuesday ****.
A tenderer who directly or indirectly canvasses support from an employee, contractor or agent of the port will be disqualified.
Tully Civic Centre External Building Remediation, Repainting and Signage Works - Cassowary Coast Regional Council is seeking quotations from suitably qualified contractors for the **** - Tully Civic Centre External Building Remediation, Repainting and Signage Works located at 34- 40 Bryant Street, Tully QLD 4854. The Works generally include external building remediation and repainting works, scaffolding and access requirements, removal and installation of signage, cleaning and preparation of external surf
External building remediation, repainting and signage works External building remediation, repainting, scaffolding, access requirements, signage removal and installation, cleaning and preparation of external surfaces.
AI helper
Cassowary Coast Regional Council seeks quotations for external building remediation, repainting, and signage works at Tully Civic Centre. The works include remediation, repainting, scaffolding, signage removal/installation, and surface preparation. A mandatory site inspection is held on 23/09/2026. Quotations must be submitted via VendorPanel by 01/10/2026 17:00 AEST. Evaluation criteria include price (30%), program (25%), methodology (25%), experience (10%), and local content (10%). The works must be completed by 31/05/2027. If Dulux paint is used, notification to Dulux is required at least 7 days prior to commencement.
The works must be completed by 31 May 2027.
Respondents must provide all required warranties, manuals, product information and handover documentation for practical completion.
Evaluation criteria weighting price 30 program 25 methodology 25 experience 10 local content 10.
Respondents are required to submit a proposed program for the works.
A site inspection is held at **** Bryant Street Tully on Wednesday 23rd September 2026 at 10:00am.
DESIGN AND CONSTRUCT - BIRKDALE COMMUNITY PRECINCT ENABLING INFRASTRUCTURE AND LAGOON SUB- PRECINCT - Redland City Council invites suitably qualified and experienced Contractors to submit Expressions of Interest ( EOI) for the Design and Construct delivery of the Birkdale Community Precinct ( BCP) Enabling Works and Lagoon Precinct. Respondents may submit an EOI for one or both project components. Enabling Works generally comprise: Bulk earthworks and site preparation works. Internal roads and associated pa
Design and construct enabling infrastructure and lagoon precinct Enabling works: bulk earthworks, site preparation, internal roads, associated pavement construction, site entry intersection works, roundabout construction, car parks, bus laydown facilities, stormwater drainage, wetlands, bioretention, water quality infrastructure, water, sewer, fire, utility infrastructure, electrical, communications, high voltage reticulation, shared pathways, pedestrian infrastructure, landscaping, signage, wayfinding, and project interface management. Lagoon precinct: large- scale public swimming lagoon ( adult/children), interactive waterplay facilities, splash zones, 1, 518m two- storey pavilion ( restaurant, cafe, retail, function spaces), public plazas, outdoor BBQ facilities, two amenities buildings ( including DDA compliant changing places), plant rooms, water treatment infrastructure, and associated landscaping/public realm.
AI helper
Redland City Council seeks Expressions of Interest (EOI) for the design and construct delivery of the Birkdale Community Precinct (BCP) enabling works and the lagoon precinct. Respondents may bid for one or both components. Enabling works include earthworks, roads, utilities, and site preparation. The lagoon precinct involves a large public swimming lagoon and associated amenities. Submissions must be electronic by 5:00 pm on Wednesday, October 7, 2026. Evaluation is non-price based, considering capability, methodology, experience, and local business benefit. A subsequent RFP process will follow.
The EOI closing date is Wednesday, October 7, 2026, at 5:00 pm. closing date and time: 5: 00pm wednesday 7th october2026
Submissions will be evaluated against criteria including capability and capacity, methodology and approach, previous experience, and local business and benefit. eoi submissions will be evaluated against the following criteria that are scored and weighted criteria: o capability and capacity o methodology and approach o previous experience o local business and benefit
Respondents must have demonstrated capability in delivering large-scale civil or aquatic infrastructure under a design and construct model. identify contractors with demonstrated capability in delivering largescale civil infrastructure and/or largescale aquatic infrastructure projects under a design and construct delivery model
A respondent who directly or indirectly canvasses support from an elected member, employee or agent of council will be disqualified. respondent must not canvas support any respondent who directly or indirectly canvasses support from an elected member, employee or agent of council will be disqualified from the process
Orchestra Pit Upgrade Construction Civic Theatre - The works comprise the refurbishment of the existing stage and orchestra pit at the Civic Theatre, including the supply and installation of new floor finishes, stage components, lighting and associated electrical works. The project includes carpeting the orchestra pit with commercial- grade carpet tiles, replacing stair carpet to match the existing finish, installing compliant emergency signage, supplying and installing new stage traps, and providing recess
Orchestra pit and stage refurbishment Refurbishment of existing stage and orchestra pit at civic theatre, including supply and installation of new floor finishes, stage components, lighting, associated electrical works, commercial- grade carpet tiles for orchestra pit, replacement stair carpet, compliant emergency signage, new stage traps, and recessed LED stage edge lighting and illuminated stair lighting.
AI helper
The project involves refurbishing the stage and orchestra pit at the civic theatre. Key works include installing new floor finishes, stage components, lighting, commercial-grade carpet tiles, new stage traps, and LED lighting. The tender submission deadline is September 9, 2026. Evaluation is based on price, quality, experience, time, and regional preference. A pre-tender briefing is available on August 24, 2026, and a second site inspection is on September 2, 2026.
Council will make payment to the contractor at the completion of the job and after successful completion of the requirements for payment. Council will make payment 30 days from the date of the invoice.
The contract will be awarded to the organisation whose tender is assessed as offering the best value. this contract will be awarded to the organisation whose tender is assessed as offering the best value.
Tenders will be evaluated on price, quality, experience, time, and regional preference. tenders will be evaluated on the following criteria: o price o quality o experience o time o regional preference rating
A pre-tender briefing will be held on Monday 24th August 2026, and a second site inspection will be held on Wednesday, 2 September 2026. a pretender briefing will be held on monday 24th august 2026 commencing at 11am.
Failure to notify and to take action to rectify modern slavery risks will result in termination of the contract. failure to notify and to take action to rectify thesituation and prevent it from occurring again will result in termination of the contract.
**** - Lambert Street Reconstruction from Drummond Street to Leschenault - SLK 0. 0- 0. 28 - Please refer to the Tender documentation and attachments - Please ensure you have addressed the selection criteria and attached with your submission
Street reconstruction Replacement of existing and installation of new stormwater drainage pits, pipes covers and grates; replacement of existing road pavement; sealing and asphalting; installation of kerbing, pram ramps, driveway aprons and crossovers; removal and installation of concrete paths; installation of road markings and signage; associated traffic management and preliminaries.
AI helper
The City of Albany seeks a civil construction contractor for the Lambert Street reconstruction project. Works must be planned to maximize activities during the school holidays (December 19, 2026, to February 1, 2027). The contractor must supply all plant, materials, and labor, manage traffic, and provide a site supervisor. The evaluation uses a best value for money approach. A mandatory site inspection is scheduled for September 1, 2026. The submission deadline is September 17, 2026, at 10:00 am AWST.
The deadline for this request is 10:00am awst, thursday 17september 2026.
Prices tendered are to be on a schedule of rates basis.
The contract shall be in force for the period until the end of the defects liability period twelve 12 months from award of practical completion.
The principal has adopted a best value for money approach to this request.
Offers that do not contain all information requested as per selection criteria will be excluded from evaluation.
Tenderers are required to attend a site inspection on tuesday 1 september 2026 at 8: 30am.
An offer may be rejected without consideration of its merits in the event that: a it is not submitted before the deadline or it is not submitted at the place specified in the request or c it fails to comply with any other requirements of the request.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
It encompasses all portals in one place.
G. Ferrea
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Excellent information. Just what I was looking for.
L. H. Borrelli
Fast, flexible, and simple.
E. Disruptivas
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
They notify me promptly when a contest is published.
L. Salazar
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
I am very satisfied; it's a very useful tool.
J. S. Garcia
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I quickly find the tenders that interest me.
S. Roque
The idea of ​​using a keyword and sending the information by email is very good.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
