Walk Tenders

The works are due to be completed by March 2027.

The evaluation panel will use a weighted point score evaluation system that allows price and nonprice criteria to be considered in the selection of a preferred tenderer.

Tenderers must provide details of licenses, accreditations, and financial capacity to be considered.

An informal briefing session is to be conducted on Tuesday, 11th August at 11am aspire estate playground and sweat track location greenslade boulevard, evanston south.

Failure to respond to, or meet any of the requirements set out in this rft, and the tender documents, will result in the tender being deemed a nonconforming tender.

The contractor is responsible for a defects liability period of 12 months from the date of practical completion. defects liability period of 12 months from the date of practical completion.

The council will have regard to, but not necessarily be limited to, completion of the form of quote and price, compliance, proposed methodology, warranties, local economic benefit, demonstrated experience, certifications, and WHS compliance. In assessing quotes, the council will have regard to, but not necessarily be limited to, the following criteria not listed in any order of priority:

The successful respondent must have minimum qualifications including construction industry white card, building licences, plant equipment licences, and traffic management. The successful respondent must have the following minimum qualifications: construction industry white card building licences plant equipment licences traffic management

Failure to submit all safe work documentation to council for approval, a minimum of two weeks prior to commencing any work onsite, is a hold point. submission of all safe work documentation to council for approval, a minimum of two 2 weeks prior to commencing any work onsite, is a hold point of this project.

A mandatory on site pre tender meeting will also be held. Details of the on site meeting will be provided at the online pre tender meeting.