Architecture Tenders

The indicative construction period is 20 weeks. Construction period 20 weeks

Contractors shall state in their quotation the period of warranty and guarantee conditions that apply against defects for the goods offered, together with any aftersales services provided.

The principal has adopted a best value for money approach to this request. he principal has adopted a best value for money approach to this request.

Offers that do not contain all information requested as per selection criteria will be excluded from evaluation. Offers that do not contain all information requested as per selection criteria will be excluded from evaluation.

If work under the contract does not reach practical completion by the date specified, liquidated damages of 500 per day will apply. if work under the contract does not reach practical completion by the date specified or an amended date if an extension of time is granted by the principal, liquidated damages of 500 per day will apply.

Tenderers are requested to attend a site inspection on friday 27 february 2026 at 11: 00am. enderers are requested to attend a site inspection on friday 27 february 2026 at 11: 00am.

The cut off for queries is 2. 00pm on11 march 2026 awst in order give all tenderers sufficient time to address additional information. he cut off for queries is 2. 00pm on11 march 2026 awst in order give all tenderers sufficient time to address additional information.

The bid notice states that the site master plan is to be completed by the end of 2026.

The bid notice states that Wagga Wagga City Council are seeking a suitably qualified and skilled service provider to complete a site master plan.

A pretender briefing will be held on Wednesday 4th March 2026 at 2pm.

The supplier query cutoff is Sunday 29 March 2026 12:00 am E. South America Standard Time.

The deadline for this request is as per the closing datetime published on vendorpanel. he closing datetime published on vendorpanel for lodgement of your deadline: response.

The contract may be awarded to a sole respondent who best demonstrates the ability to provide quality products andor services at a competitive price. he contract may be awarded to a sole respondent who best demonstrates the ability to provide quality products andor services at a competitive price.

There is no briefing or inspection for this request, however a site visit is highly recommended. here is no briefing or inspection for this request, however a site visit is highly recommended.

Written clarifications must be made using ask a question on vendorpanel and may be subject to an addendum to this request. written clarifications must be made usingask a question on vendorpanel and may be subject to an addendum to this request.

The end date is 6 months from the commencement date, which is to be determined upon contract signing. End date 6 months from commencement date tbc

The council will pay the amount of each invoice within 30 days of its receipt or 30 days after completion of the service whichever is the later except where council notifies the contractor of a dispute. council will pay the amount of each invoice within 30 days of its receipt or 30 days after completion of the service whichever is the later except where council notifies the contractor of a dispute in accordance with clause 24 of this agreement.

The contractor warrants that materials, documents, processes and other things produced by the contractor in providing the service do not and will not breach any copyright or other intellectual property rights held by a third party. he contractor warrants that materials, documents, processes and other things produced by the contractor in providing the service do not and will not breach any copyright or other intellectual property rights held by a third party.

The contract will be awarded on the basis of the best value for money, the most benefit to the community and the greatest advantage to council. he principle that underlies the awarding of all council contracts is that, following consideration and evaluation of all tenders, the contract will be awarded on the basis of the best value for money, the most benefit to the community and the greatest advantage to council.

Tenders will only be accepted from persons or organisations with whom or which it is capable of entering a contract. enders will only be accepted from persons or organisations with whom or which it is capable of entering a contract.

If the services are not provided by the end date of the contract, the designated officer shall certify as due and payable to the council, liquidated damages in the amount specified in item 12 of the schedule, for every day after the end date of the contract, until the services are provided to councils satisfaction. if the services are not provided by the end date of the contract, the designated officer shall certify as due and payable to the council, liquidated damages in the amount specified in item 12 of the schedule, for every day after the end date of the contract, until the services are provided to councils satisfaction.

Enquiries may only be made in the manner disclosed on the front page of this invitation to tender. enquiries may only be made in the manner disclosed on the front page of this invitation to tender.

The selection criteria and weightings for this project are outlined below: key evaluation criteria: weighting quotation price 40. key evaluation criteria: weighting quotation price 40