Ben Hammond Complex - Disposal of Assets, Conductor, Scrap Cable and Steel - Power and Water Corporation ( PWC) is disposing of conductor, scrap cable and steel.
ben hammond complex disposal of assets, conductor, scrap cable and steel conductor, scrap cable and steel
AI helper
The tender is for the disposal of assets including conductor, scrap cable, and steel. The closing date for submissions is March 04, 2026, at 2:00 PM ACST. A site inspection is scheduled for February 24, 2026. The goods are located at the Ben Hammond Complex in Darwin. The removal of goods must be completed within 14 days from the notice of acceptance. The minimum requirement of PPE is a hi-viz shirt, long pants, and closed-in shoes. Payment for the full amount accepted must be made within 14 days from the notice of acceptance.
The bid notice states that the datetimeframe for removal of goodswithin 14 days from notice of acceptance.
The bid notice states that payment to be made for the full amount accepted within 14 days from notice of acceptance.
The assessment criteria is price 100total 100.
The site inspection is scheduled for uesday 24 february 2026.
Transformation Study into the North West Minerals Province in Queensland - The Department of Natural Resources and Mines, Manufacturing and Regional and Rural Development ( the Department) is seeking Expressions of Interest ( EOI) from suitably qualified organisations ( or consortiums of organisations) with the knowledge, skills, experience and resources to undertake the transformation study. Potential suppliers are invited to put forward an EOI. Respondents evaluated as suitable through this EOI process wi
Transformation study into the future of copper smelting and refining and the economic potential of the north west minerals province in queensland
AI helper
The Department of Natural Resources and Mines, Manufacturing and Regional and Rural Development is seeking expressions of interest for a transformation study. Responses must be submitted electronically by February 24, 2026. The study aims to assess the economic potential of the North West Minerals Province and the future of copper smelting and refining. The evaluation criteria include technical expertise, operational capability, engagement, and value for money. A draft deliverable is required by September 30, 2026.
The bid notice states including the provision of a draft deliverable by 30 september 2026.
The bid notice states Expressions of interest will be evaluated using the following evaluation criteria: evaluation criteriacriterion 1technical and analytical expertise respondent to demonstrate: technical expertise in metallurgical and smelting processesexpertise in designing and implementing operating model improvements within heavy industry and resource operations industrial transformation and feasibility study capabilityinfrastructure and supply chain expertiseeconomic, commercial and market analysis capabilityenvironmental and regulatory understandingcriterion 2operational and delivery capabilityrespondent to provide: project management and delivery approachrelevant team qualifications and key personnelcriterion 3engagement and strategic insightrespondent to demonstrate: stakeholder engagement and communication capability including a comprehensive stakeholder engagement strategy which must include a formal submission opportunity for any interested person, and inperson community engagementlocal and regional knowledge and experienceinnovation and strategic insightcriterion 4value for moneyprice will be reviewed to ensure it is within budget and that overall value for money is being considered in achieving outcome.
The bid notice states he department is seeking expressions of interest eoi from suitably qualified organisations or consortiums of organisations with the knowledge, skills, experience and resources to undertake the transformation study.
Construction of Water Main Replacement Program 2026 - This Request for Tender ( RFT) is seeking suitable companies to tender for the Capital Works Water Main Replacement works at various locations within Dubbo Regional Council LGA. Works will include the supply and installation of all items related to the Water Main Replacement Concept Plans.
Construction of water main replacement program 2026 Works will include the supply and installation of all items related to the water main replacement concept plans. Works will include the supply and installation of all items related to the water main replacement concept plans all proposed new pipelines are illustrated in green, existing pipelines are illustrated in blue: mark out and road cutting pipe and fitting materials embedment bedding noncohesive sand, road backfill hd dgb road base with fly ash and road restoration sealing by drc. reconnection of existing copper services directly where existing pipe crosses new main or extend to new main, for tendering purposes each lot inc. commercial lots to be assumed connected to dn20 water service only hydrants to be installed every 60 mtrs and located on footpaths only see fitting diagram stop valves to be installed on all tee branches all redundant lives tees to be plated off
AI helper
The tender is for the construction of a water main replacement program. Tenders close on January 20, 2026. Mandatory site inspection is required. The tender requires the completion and submission of specific forms. The principal will give consideration to the following criteria: price, experience and capability, health, safety, environmental quality, and project management plan and methodology and program. The successful tenderer will be notified in writing within 60 days of the closing date. The principal is committed to buying from local businesses where such purchases may be justified on value for money grounds. Local suppliers and local content receive a 5% discount on price in the evaluation of tenders. The principal may be required to record details of any tender accepted in its government contracts register where the resultant contract has a value of 150,**** or more. The contractor must ensure the services are performed in a safe manner and in accordance with all relevant legislation and codes of practice. The contractor will be entitled to assign or subcontract the whole or any part of its rights and obligations under this contract only with the prior written consent of the principal. Liquidated damages rate is $1,200 per working day. The defects liability period is 52 weeks from practical completion. The contractor must prepare and submit a project specific quality management plan (QMP). The contractor must attend dubbo regional councils office for an inception meeting, plus additional quarterly meetings. The contractor must provide weekly schedule updates. The contractor must provide accurate and detailed works-as-executed AutoCAD files.
The bid notice states ime for completion weeks.
The bid notice states defects liability period 52 weeks from practical completion
The principal will give consideration to the following criteria: price, experience and capability, health, safety, environmental quality, and project management plan and methodology and program.
The bid notice states that tenders are sought from appropriately qualified and experienced companies.
The bid notice states liquidated damages rate 1,200 per working day.
The bid notice states here is no mandatory inspectionmeeting required.
Construction of Water Main Replacement Program 2026 - This Request for Tender ( RFT) is seeking suitable companies to tender for the Capital Works Water Main Replacement works at various locations within Dubbo Regional Council LGA. Works will include the supply and installation of all items related to the Water Main Replacement Concept Plans.
construction of water main replacement program 2026 Works will include the supply and installation of all items related to the water main replacement concept plans all proposed new pipelines are illustrated in green, existing pipelines are illustrated in blue: mark out and road cutting pipe and fitting materials embedment bedding noncohesive sand, road backfill hd dgb road base with fly ash and road restoration sealing by drc. Reconnection of existing copper services directly where existing pipe crosses new main or extend to new main, for tendering purposes each lot inc. commercial lots to be assumed connected to dn20 water service only hydrants to be installed every 60 mtrs and located on footpaths only see fitting diagram stop valves to be installed on all tee branches all redundant lives tees to be plated off
AI helper
The tender is for the construction of a water main replacement program. Tenders close on January 20, 2026. Mandatory site inspection is required. The principal will give consideration to price, experience and capability, health, safety, environmental quality, and project management plan and methodology and program in assessing tenders. The successful tenderer will be notified in writing within 60 days of the closing date. The schedule of lump sum shall be completed by the tenderer detailing the break up of works associated with the project. The schedule of plant and equipment shall be completed by the tenderer giving the number and type of plant proposed to be used on the work. The schedule of subcontractors shall be completed by the tenderer to nominate the name, address and relevant experience of subcontractors proposed to be engaged on the works. The schedule of manufacturers shall be completed by the tenderer giving full details of the proposed sources of all materials to be used for the work. Tenderers must submit replies to the following along with their tender otherwise their tender may be rejected: detailed schedule of rates, company principals, similar works, referees, bankers, programme, work health and safety, financial capability to undertake works, and environmental obligations.
The bid notice states that the time for completion is weeks.
The defects liability period is 52 weeks from practical completion.
In assessing tenders, the principal will give consideration to price, experience and capability, health, safety, environmental quality, and project management plan and methodology and program.
Tenders are sought from appropriately qualified and experienced companies for the carrying out of these works.
The liquidated damages rate is $1,200 per working day.
There is no mandatory inspection/meeting required.
The supplier query cutoff is Thursday 15 January 2026 08:00 pm E. South America Standard Time.
Wallaroo Aquatic Facility- ** CLOSING DATE EXTENDED TO 12th DECEMBER 2025 ** This specification details the requirements for the construction of the new Wallaroo Swimming Enclosure for the Copper Coast Council. The works include the fabrication, supply, transportation, installation, and commissioning of all marine and structural components as outlined in the approved design documentation prepared by WGA. With the drawings being issued as IFT, Council are seeking additional input and suggestions from tender
construction of the new wallaroo swimming enclosure
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Start your free trial and receive email alerts
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/territories, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits Australia (1002 real users, 03/03/2026).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
We selected the most helpful reviews from real users. Order may change periodically.
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Efficiency in search times.
R. Chavez
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
Easy to find the bids.
R. M. David
Excellent platform to help promote and expand the reach of your work.
C. Merino
With the chosen keywords, I can find many tenders of interest! I learn about new notices well in advance, giving me enough time to get organized to participate.
D. Comaq
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
It helps me identify areas of opportunity and find tenders related to my work area.
I. J. R. Beltran
It is complete and optimal, it improves my time.
R. de L. Cruz
The search tool really works and satisfactorily meets our needs.
D. L. Cairuga
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
BidHits Australia is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals every day at the Commonwealth, state/territory and local council levels. Tenders are added to the system as soon as they are published on the source portal.
Plans start at A$ 65.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia. Start by adding a few keywords. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits Australia now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1002 active users, conducted through 03/03/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".