**** Pathway and Pedestrian Bridge Eudlo Creek - Tenders are invited for the construction of a new pathway at Eudlo. Council is seeking the services of experienced Contractors to undertake the works which include, but are not limited to: o Construction of a new pedestrian bridge with a 10m span o Construction of Wooden Boardwalk; and o Concrete footpath connections and hard landscaping Council will consider Alternative Tenders when accompanied by a Conforming Tender. Under an Alternate Tender, Respondent
AI helper
Lump sum construction contract for a new pedestrian bridge (10m span), wooden boardwalk, concrete footpath connections and hard landscaping at Eudlo. Tenders due 12noon 27 October 2026 (or 2 November 2026 per website). Evaluation criteria: capability 30%, methodology 20%, social/economic 20%, price 30%. Site visit encouraged. Project expected completion by end of March 2027. Tenders submitted electronically via VendorPanel.
Project expected to be finalised prior to end of March 2027, weather permitting. this project is expected to be finalised prior to end of march 2027, weather permitting.
Evaluation criteria: capability and experience 30%, methodology 20%, social and economic factors 20%, price 30%. capability and experience 30 methodology 20 social and economic factors 20 price 30
Council seeks experienced contractors. council is seeking the services of experienced contractors to undertake the works
Respondents are encouraged to visit the publicly accessible site. respondents are encouraged to visit the publicly accessible site to familiarise themselves with the conditions, access points and surroundings
Clarifications cutoff is 3 business days prior to closing date. cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date
Prohibited contact with council members may result in disqualification. any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process
**** Drainage Projects - Multiple Locations - Ipswich City Council invites suitably experienced and qualified Contractor/s to undertake the required civil construction works at the following locations: o SP1 - Pryde and Hume Stormwater Rehabilitation Upgrade Stage 1 o SP2 - East Ipswich Stormwater Drainage Upgrade Stage 3 o SP3 - Woodend Catchment Stormwater Rehabilitation Stage 1 Tenderers have the option to bid on one, two or all 3 locations. Separate contracts will be issued for each location.
AI helper
Ipswich City Council seeks contractors for civil construction works on three stormwater drainage projects: Pryde and Hume stormwater rehabilitation upgrade stage 1, East Ipswich stormwater drainage upgrade stage 3, and Woodend catchment stormwater rehabilitation stage 1. Tenderers may bid on one, two, or all three locations, with separate contracts per location. Tenders must be lodged via the Vendor Panel portal by 17 November 2026 at 2:00 PM. Clarification requests due by 12 November 2026. Evaluation criteria include company/personnel experience, methodology, timing, and Ipswich local support. Site visits are encouraged as sites are publicly accessible.
All parks are publicly accessible. Suppliers are encouraged to visit the sites, ensuring compliance with clause 5. 3 appropriate safety requirements.
**** Pathway and Pedestrian Bridge Eudlo Creek - Tenders are invited for the construction of a new pathway at Eudlo. Council is seeking the services of experienced Contractors to undertake the works which include, but are not limited to: o Construction of a new pedestrian bridge with a 10m span o Construction of Wooden Boardwalk; and o Concrete footpath connections and hard landscaping Council will consider Alternative Tenders when accompanied by a Conforming Tender. Under an Alternate Tender, Respondent
AI helper
Lump sum construction contract for a new pedestrian bridge, wooden boardwalk, and concrete footpath connections at Eudlo. Tenders due 12noon 27 October 2026 (website shows 2 November 2026). Evaluation criteria: capability and experience 30%, methodology 20%, social and economic factors 20%, price 30%. Site visit encouraged. Project expected completion by end of March 2027. Tenders submitted electronically via VendorPanel. Clarification cutoff 3 business days before closing.
Project expected to be finalised prior to end of March 2027, weather permitting. this project is expected to be finalised prior to end of march 2027, weather permitting.
Evaluation criteria: capability and experience 30%, methodology 20%, social and economic factors 20%, price 30%. capability and experience 30 methodology 20 social and economic factors 20 price 30
Respondents are encouraged to visit the publicly accessible site. respondents are encouraged to visit the publicly accessible site to familiarise themselves with the conditions, access points and surroundings
Clarifications cutoff is 3 business days prior to closing date. cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date
Prohibited contact with local government employee or elected member may result in disqualification. any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified
**** Drainage Projects - Multiple Locations - Ipswich City Council invites suitably experienced and qualified Contractor/s to undertake the required civil construction works at the following locations: o SP1 - Pryde and Hume Stormwater Rehabilitation Upgrade Stage 1 o SP2 - East Ipswich Stormwater Drainage Upgrade Stage 3 o SP3 - Woodend Catchment Stormwater Rehabilitation Stage 1 Tenderers have the option to bid on one, two or all 3 locations. Separate contracts will be issued for each location.
AI helper
Tenders due 17 November 2026 at 2:00 PM. Three separate stormwater drainage projects in Ipswich. Tenderers may bid on one, two, or all three locations. Separate contracts per location. Tenders submitted via Vendor Panel portal. Clarification requests due 12 November 2026. Evaluation criteria include company/personnel experience, methodology, timing, and local support. Site visits encouraged as sites are publicly accessible.
All parks are publicly accessible. Suppliers are encouraged to visit the sites, ensuring compliance with clause 5. 3 appropriate safety requirements.
**** Pathway and Pedestrian Bridge Eudlo Creek - Tenders are invited for the construction of a new pathway at Eudlo. Council is seeking the services of experienced Contractors to undertake the works which include, but are not limited to: o Construction of a new pedestrian bridge with a 10m span o Construction of Wooden Boardwalk; and o Concrete footpath connections and hard landscaping Council will consider Alternative Tenders when accompanied by a Conforming Tender. Under an Alternate Tender, Respondent
AI helper
Lump sum construction contract for a new pedestrian bridge (10m span), wooden boardwalk, and concrete footpath connections at Eudlo. Tenders due 12noon 27 October 2026 (local time) via VendorPanel. Evaluation criteria: capability 30%, methodology 20%, social/economic 20%, price 30%. Site visit encouraged. Project expected completion by end of March 2027. Clarifications cutoff 3 business days before closing. Alternative tenders considered with conforming tender.
Project expected to be finalised prior to end of March 2027, weather permitting. this project is expected to be finalised prior to end of march 2027, weather permitting.
Evaluation criteria: capability and experience 30%, methodology 20%, social and economic factors 20%, price 30%. capability and experience 30 methodology 20 social and economic factors 20 price 30
Council seeks experienced contractors. council is seeking the services of experienced contractors to undertake the works
Respondents are encouraged to visit the publicly accessible site. respondents are encouraged to visit the publicly accessible site to familiarise themselves with the conditions, access points and surroundings
Clarifications cutoff is 3 business days prior to closing date. cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date
Prohibited contact with council members may result in disqualification. any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
