Bathroom Repair Tenders

The closing date for this quotation tender is 16th July 2026 at 2 PM.

The contractor will be paid within 30 days of receiving a valid tax invoice, provided satisfactory evidence of completed works is received. Payment is lump sum on completion, with progress claims considered upon request.

A defect liability period of 12 months from the completion date is required.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. The quoted price and relevant non-price criteria will be assessed together to determine the most advantageous outcome for the principal.

Respondents must complete the quotation form and response schedules. All work must be carried out by experienced and licensed personnel. The contractor must warrant that all personnel and/or subcontractors engaged are appropriately insured, qualified, competent, experienced, and hold all necessary licenses, permits, and authorisations.

If works are not completed within the requested timeframe, TSIRC nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.

Attendance at site inspection is listed as 'na' (not applicable).

Supplier query cutoff is Friday 17 July 2026, 01:00 AM.

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended, the RFQ will be classed as non-conforming. If the quotation form and response schedules are not completed (items 7. 1 through to 7. 8), the RFQ will be classed as non-conforming.

The closing date for this quotation tender is 16th July 2026 at 2pm.

The contractor will be paid by TSIRC within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. Payment is lump sum on completion, with progress claims considered upon request.

The defect liability period is 12 months from the completion date.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. The quoted price and relevant non-price criteria will be assessed together to determine the most advantageous outcome for the principal.

All work must be carried out by experienced and licensed personnel in the field of work specified. The contractor must warrant that all personnel and/or subcontractors engaged to provide the works are appropriately insured, qualified, competent, experienced and hold all necessary licences, permits and authorisations.

Attendance at site inspection is not applicable (NA).

Supplier query cutoff is Friday 17 July 2026 at 01:00 am.

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended, the RFQ will be classed as non-conforming. If the quotation form and response schedules are not completed (items 7. 1 through to 7. 8), the RFQ will be classed as non-conforming.

The RFQ closes on Monday 29 June 2026 01:00 am E. South America Standard Time.

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the RFQ will be classed as non-conforming. If the quotation form and response schedules are not completed the RFQ will be deemed as non-conforming (items 7. 1 through to 7. 8).

The closing date for submissions is June 26, 2026, at 2 PM.

Payment is lump sum on completion. Progress claims will be considered upon request. The contractor will be paid within 30 days of receiving a valid tax invoice. The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.

The defect liability period is 12 months from the completion date. The contractor must, at no additional cost, remedy any defect in the works within 30 days of being notified by tsirc.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. The quoted price and relevant non-price criteria will be assessed together to determine the most advantageous outcome for the principal. he quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome for the principal.

Respondents must complete the quotation form and response schedules. All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified.

Attendance at site inspection is not applicable (NA).

Supplier query cutoff is Friday 26 June 2026 at 01:00 am.

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended, the RFQ will be classed as non-conforming. If the quotation form and response schedules are not completed, the RFQ will be classed as non-conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming

The tender closes on Wednesday, 24 June 2026 at 04:00 am E. South America Standard Time.

The successful contractor must provide manufacturer warranties and guarantees, operating manuals, and compliance documentation for supplied equipment and appliances.

Tenders will be evaluated by reference to the sound contracting principles: value for money, open and effective competition, the development of competitive local business and industry, environmental protection, and ethical behaviour and fair dealing.

The principal will rely upon the tenderer having independently verified any information provided and satisfied itself that its tender complies in all respects with the requirements of the conditions of tender.

The supplier query cutoff is Monday, 22 June 2026 at 04:00 am E. South America Standard Time.

A tender may be rejected if the tender response is not fully completed or does not include all supporting documents and materials required.