Cemetery Tenders

The deadline for lodgement of submissions is Friday, 26 June 2026, at 2:00 PM AWST. The deadline for lodgement of submissions, as detailed on the front cover of this request for tender.

Progress claims are to be submitted by the 3rd day of the month for works completed in the month prior. Progress claimsto be submitted by the 3rd day of the month for works completed in the month prior.

A 12-month defects liability period from the date of practical completion is required. defects liability period12 months from the date of practical completion

The contract may be awarded to the respondent who best demonstrates the ability to provide quality products and/or services at a competitive price, using a best value for money approach. The principal has adopted the best value for money approach to this request.

Respondents must be suitably qualified contractors. Evidence of holding a current building licence is required if successful. he town of port hedland is seeking a suitably qualified contractor

Liquidated damages for late completion are set at $105 per day. Liquidated damages ratebased on potential losses associated with late completion: 105 per day

A non-mandatory site inspection will be held on Tuesday, 09 June 2026, at 10:00 AM AWST at Cemetery Beach Park East Ablutions. site inspection nonmandatorytime: 10:00am awstdate: tuesday, 09 june 2026location: cemetery beach park east ablutions

Supplier queries have a cutoff date of Wednesday, 24 June 2026, 03:00 AM E. South America Standard Time. supplier query cutoff wednesday 24 june 2026 03: 00 am e. south america standard time

Submissions not lodged by the deadline, not submitted at the specified place, or lacking a completed and signed offer form with all required attachments may be rejected. a response will be rejected without consideration of its merits in the event that: it is submitted after the deadline

Tenders must be submitted by 5pm on 1 July 2026.

Tenders are invited from suitably qualified civil construction contractors.

A site inspection is mandatory and will be held at Wujal Wujal Cemetery on 17 June 2026 at 11 am. RSVP to ***@***. *. * by 12 June 2026.

The deadline for submissions is Friday, 26 June 2026, at 2:00 PM AWST.

Progress claims are to be submitted by the 3rd day of the month for works completed in the month prior. The basis for this contract will be fixed price.

The defect liability period is 12 months from the date of practical completion. The contractor will also be required to provide operation and maintenance manuals, including warranty periods for supplied assets.

The contract may be awarded to a single respondent who best demonstrates the ability to provide quality products and/or services at a competitive price, using a best value for money approach.

The Town is seeking a suitably qualified contractor. Respondents must demonstrate relevant experience, capacity to deliver, and a demonstrated understanding of the methodology.

Liquidated damages for late completion are set at $105 per day.

A non-mandatory site inspection will be held on Tuesday, 09 June 2026, at 10:00 AM AWST at Cemetery Beach Park East Ablutions.

Supplier query cutoff is Wednesday, 24 June 2026, 03:00 AM E. South America Standard Time.

Submissions received after the deadline, not submitted at the specified place, or incomplete may be rejected. Tenders found to contain viruses may be excluded.