D& R Airconditioning Supply and Install- Port Pirie Regional Council invites submissions for the replacement of the air conditioning system servicing the Development and Regulation ( D& R) Section of the Main Administration Building, located at 115 Ellen Street, Port Pirie SA ****, as detailed in this Request for Tender ( RFT). The works comprise the removal of the existing air conditioning system and the supply and installation of a replacement system in accordance with the design and specifications contai
Air conditioning system replacement Removal and disposal of existing air conditioning system; supply, installation, and commissioning of a new air conditioning system.
AI helper
The Port Pirie Regional Council invites tenders for the removal of the existing air conditioning system and the supply and installation of a replacement system at the main administration building (DR section). The closing date is 15 October 2026 at 2:00 pm Adelaide time. Tenderers must undertake a site inspection prior to submission, which must be arranged before 8 October 2026. The evaluation uses a weighted point score system considering price and non-price criteria. The preferred completion date is 15 January 2027.
The council must pay to the contractor, within thirty 30 days of the end of the month in which the practical certificate is issued, the agreed sum as adjusted by this agreement.
The defects liability period for the works commences upon practical completion of the works and continues until expiry of the period stated in item 8 of the schedule.
The evaluation panel will use a weighted point score evaluation system that allows price and nonprice criteria to be taken into account in the selection of a preferred tenderer.
Each tenderer must if applicable be licensed or registered to perform the services.
If the works do not reach practical completion by the date for practical completion, and no extension of time has been granted, liquidated damages will be due and payable to the council as set out in item 17 for every day after twentyone 21 days from the date for practical completion to and including the earliest of the date of practical completion or termination of this agreement or the council taking all remaining works out of the hands of the contractor.
Site inspections tenderers are encouraged to undertake a site inspection prior to submitting a tender. site visits may be arranged by contacting alan bennett.
Satellite System Operation/ Mission Control Centres
Provision of Meosar Services - Provision of MEOSAR Ground Segment and Nodal MCC Services- Provision of MEOSAR Ground Segment and Nodal MCC Services In accordance with this RFI, AMSA invites Respondents to provide information and cost estimations as set out in Schedules 1 - 3. This RFI has been prepared and released by the AMSA for information gathering purposes only.
Meosar ground segment and nodal mcc services
AI helper
AMSA invites respondents to provide information and cost estimations for the provision of dedicated Meosar ground segment and nodal MCC services. This RFI is for information gathering only, and participation does not create obligations. The response closing time is 12 October 2026 at 2:00 pm Canberra local time. The current contract expires in September 2029, and a new contract is aimed for commencement in September 2029. Respondents must outline their experience and provide cost estimations for three scenarios.
The response closing time is 12 October 2026 at 2:00 pm Canberra local time. response closing time 12 oct 2026
Contract payments will likely comprise an annual fee for the provision of service delivery, paid monthly. contract payments will likely comprise an annual fee for the provision of service delivery provision of systems, operation, maintenance and through life support, paid monthly.
Respondents are invited to submit written responses that outlines their experience in designing, providing, commissioning, operating and maintaining meosar ground segment and nodal mcc systems. respondents are invited to submit written responses that outlines their experience in designing, providing, commissioning, operating and maintaining meosar ground segment and nodal mcc systems
The annual fee will be subject to performance-based abatement for service levels below the required standard. the annual fee will be subject to performancebased abatement for service levels below the required standard.
Sodium Hypochlorite Dosing System/ Supervisory Control And Data Acquisition
Design & Construction of Murrayville Chlorinator Upgrade - GWMWater invites suitably qualified and experienced contractors to submit tenders for the Design & Construction of a new sodium hypochloritedosing system in Murrayville, Victoria. Contract scope includes: Design, supply and build a new insulated dosing shed ( 3. 1 m x 3. 1 m). Design, supply and install two dosing pumps and its associated pipework. Design, supply and install a **** L chemical storage tank under a Skillion roof. Design and construct
Chlorinator upgrade Design, supply and build a new insulated dosing shed ( 3. 1 m x 3. 1 m); design, supply and install two dosing pumps and associated pipework; design, supply and install a **** l chemical storage tank under a skillion roof; design and construct a new chemical delivery bund and a site access driveway; design, supply and install a new SCADA cubicle including electrical connections; preparation of functional description and SCADA programming; complete connections and testing commissioning of new dosing station; preparation of new civil, mechanical and electrical drawings; disconnection and disposal of old dosing shed and components.
AI helper
Contractors are invited to tender for the design and construction of a new sodium hypochlorite dosing system in Murrayville, Victoria. The scope includes building a dosing shed, installing dosing pumps and a chemical storage tank, constructing a bund and driveway, and commissioning the new dosing station. The tender closes on 14 October 2026 at 02:00 pm. A noncompulsory pretender site inspection is available on 30 September 2026.
A noncompulsory pretender site inspection will be held 11 am on wednesday 30 september 2026 at 40 reed street, murrayville vic ****.
Substation Control Room/ Control Metering/ Electrical Systems
Protection Cubicles, Mounting and Blanking Plates - ***** The Contact Officer will be on leave from 21/09/2026 to 25/09/2026 inclusive. ***** Notice of the upcoming tender for the supply of protection cubicles, blanking and mounting plates - **** Energy Queensland Limited ( EQL) anticipates releasing a Request for Tender ( RFT) via SAP Ariba on or around 16/09/2026. Background and Context The purpose of this RFT is to select one or a range of capable and experienced suppliers under an arrangeme
Energy Queensland Limited (EQL) is releasing an RFT for the supply of protection cubicles, blanking, and mounting plates. The RFT is anticipated around 16/09/2026 via SAP Ariba and closes on 19 November 2026. Suppliers must comply with various Australian and international standards, including AS/NZS ISO 9001:2016. Samples must be submitted when requested. The contact officer will be on leave from 21/09/2026 to 25/09/2026.
Sample delivery must be on or before 19 November 2026. sample delivery on or before: 19 november 2026.
Contractors must provide documentary evidence concerning the level of quality system certification associated with the contractor and/or manufacturer. documentary evidence shall be provided concerning the level of quality system certification associated with the contractor and/or manufacturer
When requested, production samples of each item shall be submitted to the customer. when requested, production samples of each item shall be submitted to the customer.
If found to have supplied asbestos containing materials, the contractor shall be liable for claims from staff and the public. the contractor, if found to have supplied asbestos containing materials, shall be liable for:
Rollingstock technical advisory services, project management, engineering services Rollingstock technical advisory services for fitment of new 5G future railway mobile communication system FRMCS radios and associated ETCS baseline upgrade across the NGR and QTMP fleets.
AI helper
The procurement seeks technical advisory services for the fitment of new 5G FRMCS radios and ETCS baseline upgrades on NGR and QTMP fleets. The role involves integrated planning, design, procurement, testing, and assurance activities. The service is primarily located in the project office at 140 Creek Street, Brisbane. The contract terms are for an initial period of 3 years with extension options.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
It encompasses all portals in one place.
G. Ferrea
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Excellent information. Just what I was looking for.
L. H. Borrelli
Fast, flexible, and simple.
E. Disruptivas
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
They notify me promptly when a contest is published.
L. Salazar
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
I am very satisfied; it's a very useful tool.
J. S. Garcia
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I quickly find the tenders that interest me.
S. Roque
The idea of ​​using a keyword and sending the information by email is very good.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
