Port of Mackay & Hay Point - Pilot Vessel Launch Services - Refer to the attached Tender documents
Pilot vessel launch services at the Port of Mackay and Port of Hay Point Pilot vessel services, vessel charter, vessels
AI helper
Tender for pilot vessel launch services at Port of Mackay and Port of Hay Point. Tenders due 2:00pm on 13 November 2026 via VendorPanel or email. Site visits scheduled for 28 October 2026, optional but attendance confirmation required by 26 October 2026. PPE required for site visit. Enquiries to ***@***. *. * handled per NQBP complaints handling procedure.
Tenders must be lodged before 2:00pm on 13 November 2026, as stated: tenders must be lodged before 2:00pm on 13 november 2026.
Site visits scheduled for 28 October 2026, with confirmation required by 26 October 2026: site visits have been scheduled for wednesday 28th october 2026.
**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
AI helper
Charters Towers Regional Council invites tenders for the Weir Tower Access Walkway Replacement project. Scope includes removal and demolition of existing structural steel walkway, platform and handrails, and maintenance of existing steel trestles via abrasive blasting and painting. Contract is construct only, lump sum, under **** completion due 25 March 2027. Security: two unconditional bank guarantees at 5% of contract sum. Liquidated damages $500 per day. Defects liability period 12 months. Contact Paul Weston on 07 **** **** close 24 November 2026.
Practical completion is due by 25 March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts. The contract states: times for progress claims 21st day of each month.
Tenders are invited from suitably qualified respondents to complete the works, as stated in the request details.
Liquidated damages are set at $500 per day for delay, as stated: liquidated damages, rate subclause 34. 7 500 per day.
Supplier query cutoff is Thursday 19 November 2026, as stated: supplier query cutoff thursday 19 november 2026 04: 00 am.
Airport Management EOI - Airport Management EOI - The City of Ballarat invites Expressions of Interest to lease a Flight Training & Operations building ( with offices/classrooms) and/or the adjoining apron within an established, secure aviation precinct at Ballarat Airport. Flight Training & Operations building and/or adjoining aircraft apron; Ballarat Airport, 24 Kittyhawk Close, Mitchell Park VIC ****- Located just over an hour north- west of Melbourne, Ballarat is one of Australia' s fastest- growin
Lease of flight training & operations building and/or adjoining aircraft apron at Ballarat Airport Flight training & operations building with offices/classrooms, adjoining aircraft apron
AI helper
City of Ballarat invites expressions of interest to lease a flight training & operations building (with offices/classrooms) and/or adjoining apron at Ballarat Airport, 24 Kittyhawk Close, Mitchell Park VIC **** term is 5 years with 3 further terms of 5 years each, subject to council contracts committee decision. Permitted use includes various aviation related activities: flight training, nonscheduled air transport operations, aircraft maintenance, hangarage and associated uses. Rent payable monthly plus GST. CPI adjustments to Melbourne figures. Bank guarantee may be required. Tenant responsible for repairs, maintenance, insurance (public liability $10 million), rates and taxes. EOI closes 11 January 2027.
Rent is payable monthly in advance, as stated: rent: . per annum plus gst payable monthly.
Interest applies on late payments: interest at the rate per annum equal to the current rate fixed under section 2 of the penalty interest rates act **** vic plus 2 per annum on any money payable by the tenant under this lease and remaining unpaid after the due date.
Port of Mackay & Hay Point - Pilot Vessel Launch Services - Refer to the attached Tender documents
Pilot vessel launch services at the Port of Mackay and Port of Hay Point Pilot vessel services, vessel charter, vessels
AI helper
Tender for pilot vessel launch services at Port of Mackay and Port of Hay Point. Tenders due 13 November 2026 at 2:00pm via VendorPanel or email. Site visits scheduled 28 October 2026, attendance confirmation required by 26 October 2026. PPE required. Grievances handled per NQBP complaints procedure.
Site visits have been scheduled for Wednesday 28th October 2026, as per the below listed time: 1:00pm AEST meeting at NQBP Mackay Port Operations Centre.
**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
AI helper
Charters Towers Regional Council invites tenders for the Weir Tower Access Walkway Replacement project. Scope includes demolition of existing structural steel walkway, platform and handrails, and replacement of the elevated walkway. Existing steel trestles will be maintained, abrasive blasted and painted. Contract is construct only, lump sum, based on **** completion due 25 March 2027. Liquidated damages $500 per day. Defects liability period 12 months. Security: two unconditional bank guarantees of 5% each. Public liability insurance minimum $20,000,000. Contact Paul Weston on 07 **** **** closes 24 November 2026.
Practical completion is due by 25th March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts. The contract states: payment period means: if the contract is a building contract, 15 business days.
Tenders are invited from suitably qualified respondents and the contract requires standard risk prequalified suppliers for the weir tower access walkway replacement project.
Liquidated damages are $500 per day for delay, as stated: liquidated damages, rate subclause 34. 7 500 per day.
Contractor must not engage in improper conduct including collusive tendering, anticompetitive conduct, or any other unlawful or unethical conduct as defined in the contract.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".