This Request for Quotation (RFQ) is for a bathroom upgrade at Lot 90 Phillemon Street, Warraber. The closing date for submissions is 29th June 2026 at 2pm. Submissions can be lodged via the Vendor Panel portal or by email. The contract will be awarded to the respondent who best demonstrates best value for money, considering both price and non-price criteria. If the lump sum price breakdown schedule is amended, the RFQ will be considered non-conforming. Similarly, if the quotation form and response schedules are not completed, the RFQ will be deemed non-conforming. All specifications are attached for download. The defect liability period is 12 months from completion. The contractor must hold public and product liability insurance of $20,000,000.
The closing date for submissions is 29th June 2026 at 2pm. closes monday 29 june 2026 01:00 am e. south america standard time
Payment will be made within 30 days of receiving a valid tax invoice, provided satisfactory evidence of completed works is received. he contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants that the works will be free from defects and fit for purpose. A defect liability period of 12 months from completion date applies. defect liability period 12 months from completion date
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money, with the quoted price and relevant non-price criteria assessed together. he engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
Respondents must complete the quotation form and response schedules. The contractor must warrant that all personnel and subcontractors are appropriately insured, qualified, competent, experienced, and hold all necessary licenses. all work must be carried out by experienced and licensed personnel in the field of work specified.
If works are not completed within the requested timeframe, TSIRC nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.
Attendance at site inspection is listed as 'na'. attendance at site inspection na
If the line breakdowns for the lump sum price breakdown schedule have been amended, the RFQ will be classed as non-conforming. If the quotation form and response schedules are not completed, the RFQ will be deemed as non-conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.
