Kerb replacement program Replacement of kerb and water table, inclusive of crossover and spoon drain; nine roads require kerb replacement: Afford Road, Alice Street, Barnes Street, Bowman Street Crystal Brook, Binney Street, Broadway Road Alice Street intersection kerb and spoon, Burt Street crossover and kerb, Dunstone Street crossover spoon and kerb, Grey Terrace
AI helper
Tenders for kerb replacement program in Port Pirie and Crystal Brook. Works include kerb, water table, crossover and spoon drain replacement across nine roads. Completion by February 2027. Tenders must be lodged electronically via www. ***. *. * before 2:00pm Adelaide time on 22 October 2026. Evaluation criteria include price (45%), experience (15%), implementation/delivery schedule (20%), WHS and risk management (10%), local economic benefit/social inclusion (10%). Site briefings may be arranged prior to 15 October 2026. Enquiries to Alan Bennett, Project Manager, abennett@pirie. sa. gov. au.
Works must be completed before February 2027. The date for completion is specified as February 2027 in the schedule. councils aims for the works to be completed before the month of february 2027
The council must pay the agreed sum within 30 days of the end of the month in which the practical certificate is issued. the council must pay to the contractor, within thirty 30 days of payment of agreed sum the end of the month in which the practical certificate is issued
Defects liability period is 52 calendar weeks commencing on practical completion of the works. defects liability period 52 calendar weeks commencing on practical completion of the works
Evaluation uses a weighted point score system with price (45%), experience (15%), implementation/delivery schedule (20%), WHS and risk management (10%), local economic benefit/social inclusion (10%). the evaluation panel will use a weighted point score evaluation system that allows price and nonprice criteria to be taken into account
Each tenderer must be licensed or registered to perform the services. each tenderer must if applicable be licensed or registered to perform the services
Liquidated damages are not applicable for this contract. liquidated damages not applicable
Site briefings may be conducted if requested, arranged prior to 15 October 2026. the council may conduct a site briefing if requested. requests for a site briefing can be made by contacting alan bennett
Tenders received after the closing date will not be considered or accepted. tenders received after the closing date will not be considered or accepted
Weed Spraying on Verges Select Areas- The City of Mitcham (" Council") invites tenders for the provision of weed spraying on verges ( Select areas) ( the " Services"). The purpose of these services is to maintain the aesthetics and safety of public spaces in the City of Mitcham. This is achieved through the control of weeds on roadside verges and must include all median strips, roundabouts ( un- landscaped), laneways and unmade roadways or other specified areas, where there are not established lawns or gard
Weed spraying services on verges in select areas Weed control on roadside verges, median strips, roundabouts ( un- landscaped), laneways, unmade roadways, paved footpaths, bitumen footpaths, kerb and water tables
AI helper
City of Mitcham Council invites tenders for weed spraying on verges in select areas. Services include control of weeds on roadside verges, median strips, roundabouts, laneways, unmade roadways, and constructed surfaces like footpaths and kerbs. Tender code ****, contract number **** available for download. Contact Jason De Vries. Tender state is open.
Bulky Waste Supplementary Services - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the Service Provider to provide appropriate vehicle/s and labour to perform Supplementary bulky waste collections in the Muswellbrook Shire LGA.
Bulky waste supplementary collections service Stream 1: Scrap metal ( ferrous and nonferrous metals), whitegoods ( dryers, washing machines, dishwashers, stoves), barbeques, pushbikes, wheelbarrows, metal furniture, electric hot water systems, fridges, freezers, air conditioners or heat pump units requiring degassing. Stream 2: Hard waste ( couches, sofas, tables, chairs, bookshelves, wardrobes), floor coverings ( carpet, rugs), sporting goods, camping equipment. Gassed appliances must be collected intact.
AI helper
The service provider must supply vehicles and labour for supplementary bulky waste collections in the Muswellbrook Shire LGA, supporting a bookable service trial. Collections are envisaged on Tuesdays, handling overflow bookings up to a daily cap of 23. Acceptable items are categorized into Stream 1 (scrap metal, whitegoods, etc. ) and Stream 2 (furniture, hard waste). All materials must be delivered to the Muswellbrook waste recycling facility between 08:00 and 16:00. The contract is a schedule of rates contract. Submissions must be lodged electronically via the gotomarket platform by 25 September 2026 at 2pm.
Quotations will be assessed based on mandatory compliance, weighted price evaluation criteria, experience and capability, capacity and experience of tenderers, proposed personnel, work health and safety capability and performance, local content, management of subcontractors, modern slavery, sustainability, and customer service.
Respondents must be appropriately qualified and experienced, and all vehicles must be registered and insured with operators holding a valid NSW drivers licence.
Bulky Waste Supplementary Services - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the Service Provider to provide appropriate vehicle/s and labour to perform Supplementary bulky waste collections in the Muswellbrook Shire LGA.
Bulky waste supplementary collections service Stream 1: Scrap metal ( ferrous and nonferrous metals), whitegoods ( dryers, washing machines, dishwashers, stoves), barbeques, pushbikes, wheelbarrows, metal furniture, electric hot water systems, fridges, freezers, air conditioners or heat pump units requiring degassing. Stream 2: Hard waste ( couches, sofas, tables, chairs, bookshelves, wardrobes), floor coverings ( carpet, rugs), sporting goods, camping equipment. Gassed appliances must be collected intact.
AI helper
The service provider must supply vehicles and labour for supplementary bulky waste collections in the Muswellbrook LGA, primarily on Tuesdays, to support a bookable waste service trial. Collections must be transported to the Muswellbrook waste recycling facility (252 Coal Road). Stream 1 includes scrap metal and whitegoods; Stream 2 includes furniture and hard waste. Collection hours are 06:00 to 18:00. Quotations must be lodged electronically via the Gotomarket platform by 25 September 2026, 2pm. Assessment includes mandatory compliance and weighted criteria.
Quotations will be assessed based on weighted criteria including experience, capability, and price. weighted price evaluation criteria experience and capability capacity and experience of the tenderers proposed personnel work health and safety capability and performance local content management of the proposed subcontractors if any modern slavery sustainability of the submission and customer service
Respondents must be appropriately qualified and experienced. submissions from appropriately qualified and experienced respondents for the service provider to provide appropriate vehicles and labour
Bulky Waste Supplementary Services - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the Service Provider to provide appropriate vehicle/s and labour to perform Supplementary bulky waste collections in the Muswellbrook Shire LGA.
Bulky waste supplementary collections service Stream 1: Scrap metal ( ferrous and nonferrous metals), whitegoods ( dryers, washing machines, dishwashers, stoves), barbeques, pushbikes, wheelbarrows, metal furniture, electric hot water systems, fridges, freezers, air conditioners or heat pump units requiring degassing. Stream 2: Hard waste ( couches, sofas, tables, chairs, bookshelves, wardrobes), floor coverings ( carpet or rugs rolled and tied), sporting goods and camping equipment. Gassed appliances must be collected intact.
AI helper
The service provider must supply vehicles and labour for supplementary bulky waste collections in the Muswellbrook LGA, primarily on Tuesdays, to support a bookable waste service trial. Acceptable items are categorized into Stream 1 (scrap metal, whitegoods, etc. ) and Stream 2 (furniture, hard waste, etc. ). Gassed appliances must be collected intact. All materials must be delivered to the Muswellbrook waste recycling facility between 08:00 and 16:00. Submissions must be lodged electronically via the Gotomarket platform by 25 September 2026 at 2pm. Evaluation includes mandatory compliance, weighted price, experience, and capability.
Quotations will be assessed based on weighted price evaluation criteria including experience, capability, and sustainability. weighted price evaluation criteria experience and capability capacity and experience of the tenderers proposed personnel work health and safety capability and performance local content management of the proposed subcontractors if any modern slavery sustainability of the submission and customer service
Respondents must be appropriately qualified and experienced. submissions from appropriately qualified and experienced respondents for the service provider to provide appropriate vehicles and labour to perform supplementary bulky waste collections
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 30.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".