Stair Access Tenders

Failure to comply with submission format may result in a nonconforming offer. Failure to comply with this requirement may result in a nonconforming offer.

Works are required to be completed by 15th January 2027. The RFQ states: works are required to be completed by 15th january 2027.

Respondents must hold a building work contractor license and relevant trade licenses. The RFQ states: individuals and companies must be licensed building work contractors as per the building classification and types of building work required in this rfq.

An informal briefing session is scheduled. The RFQ states: an informal briefing session will be held at **** on thursday 22 october 2026 at the gawler sport and community centre.

Quotes received after the closing date will not be considered. The RFQ states: quotes received after the closing date will not be considered.

Practical completion is required by 30 June 2027. The contract states: the principals requirement is for separable portion 1 and separable portion 2 to achieve practical completion by 30 june 2027.

Progress claims are due on the 21st day of each month. The contract states: times for progress claims 21st day of each month in which wuc is carried out up to and including the month in which practical completion is reached.

The contractor warrants that all goods supplied will be new and free from defects. The contract states: at the time at which they are first supplied, installed or incorporated, be new and be free from defects and of merchantable quality.

Tenderers must demonstrate relevant experience. The request states: tenderers must demonstrate experience in design and construct building projects, refurbishment of occupied facilities, roof replacement works and public building extensions.

Liquidated damages are set at $1,000 per day. The contract states: liquidated damages, rate subclause 34. 7 **** per day.

A mandatory site inspection will be conducted. The request states: a mandatory site inspection will be conducted as detailed within the tender documentation.

Failure to attend the mandatory site inspection may be a risk. The request states: a mandatory site inspection will be conducted as detailed within the tender documentation.

Works are required to be completed by 15th January 2027. The RFQ states: works are required to be completed by 15th january 2027.

Licensed building work contractors are required. The RFQ states: individuals and companies must be licensed building work contractors as per the building classification and types of building work required in this rfq.

An informal briefing session is available. The RFQ states: an informal briefing session will be held at **** on thursday 22 october 2026 at the gawler sport and community centre.

Quotes received after the closing date will not be considered. The RFQ states: quotes received after the closing date will not be considered.

The principal's requirement is for separable portion 1 and separable portion 2 to achieve practical completion by 30 June 2027. the principals requirement is for separable portion 1 and separable portion 2 to achieve practical completion by 30 june 2027

Progress claims are due on the 21st day of each month for work done to that date. Interest on overdue payments is 7% per annum. progress claims subclause 37. 1 1. times for progress claims 21st day of each month

The contractor warrants that all plant, equipment, materials and goods supplied will be new, free from defects, and comply with the contract and relevant Australian standards. all plant, equipment, materials, parts, consumables or other goods supplied. . . shall. . . be free from defects and of merchantable quality

Tenderers must demonstrate experience in design and construct building projects, refurbishment of occupied facilities, roof replacement works and public building extensions. tenderers must demonstrate experience in design and construct building projects, refurbishment of occupied facilities, roof replacement works and public building extensions

Liquidated damages are $1,000 per day for each separable portion. liquidated damages, rate subclause 34. 7 **** per day

A mandatory site inspection will be conducted as detailed within the tender documentation. a mandatory site inspection will be conducted as detailed within the tender documentation

Contractors must not engage in improper conduct, including collusive tendering, anticompetitive conduct, or any other unlawful or unethical conduct. engaging in any collusive tendering, anticompetitive conduct, or any other unlawful or unethical conduct