The Torres Strait Island Regional Council is seeking quotations for external works, specifically stairs handrail replacement at Lot 55d Warria Street, Mabuiag. The closing date for submissions is July 6th, 2026, at 2 PM. Submissions can be made via the Vendor Panel portal or by email. The evaluation will be based on best value for money, considering both price and non-price criteria. All specifications are attached for download. A lump sum price breakdown schedule must be completed, and any amendments will render the RFQ non-conforming. Failure to complete quotation forms and schedules (items 7. 1 to 7. 8) will also result in non-conformance. The defect liability period is 12 months. Public and product liability insurance of $20,000,000 is required.
The closing date for submissions is July 6th, 2026, at 2 PM. closes monday 06 july 2026 01: 00 am e. south america standard time
Payment will be made within 30 days of receiving a valid tax invoice, provided satisfactory evidence of completed works is received. he contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
A defect liability period of 12 months from the completion date is required. defect liability period 12 months from completion date
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money, with the quoted price and relevant non-price criteria assessed together. he engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
Respondents must provide an overview of their experience and past performance in projects of similar nature, scope, and size, as well as details of the experienced personnel involved and current contractual work commitments. provide an overview of contractors experience and past performance in projects of similar nature, scope and size.
If the contractor fails to provide any agreed deliverable or complete any agreed milestone, they must use all reasonable endeavors to correct the issue at no additional cost to TSIRC. if the contractor fails to provide any agreed deliverable, or complete any agreed milestone, you must use all reasonable endeavours to correct the issue which caused the failure, at no additional cost to tsirc.
Attendance at site inspection is not applicable. attendance at site inspection na
The supplier query cutoff is Monday, July 6th, 2026, at 1:00 AM. supplier query cutoff monday 06 july 2026 01: 00 am e. south america standard time
The RFQ will be deemed non-conforming if line breakdowns in the lump sum price breakdown schedule are amended or if the quotation form and response schedules (items 7. 1 through to 7. 8) are not completed. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be deemed as non- conforming. if the quotation form and response schedules are not completed the rfq will be deemed as non- conforming ( items 7. 1 through to 7. 8).
