Infrastructure Canberra is seeking to engage a suitably qualified metal and Acrylonitrile Butadiene Styrene ( ABS) plastic fabricator to manufacture the following equipment which will be installed on the new Canberra Light Rail Stage 2A stops: Stainless steel Ticket Vending Machine Cabinets and stainless- steel Platform Validator Plinths and the associated componentry; and ABS plastic shrouds which will be affixed to the Ticket Vending Machine Cabinets and Platform Validator Plinths. As part of the works, t
The procurement involves works to cover the construction of a Wombat crossing at Boddington Cr Kambah, and a Pedestrian Crossing ( Zebra) at Bauhinia St O Connor. The works also include but are not limited to earthworks, removal of existing kerb and path infrastructure, concrete works, streetlighting, asphaltic concrete pavement works including formation of a raised platform, barrier railing installation, Traffic Control Devices and landscaping ( Works ).
Infrastructure Canberra is seeking to engage a suitably qualified metal and Acrylonitrile Butadiene Styrene ( ABS) plastic fabricator to manufacture the following equipment which will be installed on the new Canberra Light Rail Stage 2A stops: Stainless steel Ticket Vending Machine Cabinets and stainless- steel Platform Validator Plinths and the associated componentry; and ABS plastic shrouds which will be affixed to the Ticket Vending Machine Cabinets and Platform Validator Plinths. As part of the works, t
fabrication of tvm cabinets, pv plinths and componentry
AI helper
The appointed contractor will be required to finalise detailed design based on the territory governments concept designs, provide issue for construction drawings, fabricate and deliver the complete fabricated equipment to canberra, act. The tender closes at 3 march 2026 02: 00 pm.
RFQ2026/30 4 x 2 LightTruck - Cootamundra- Gundagai Regional Council is seeking quotations for a 4 x 2 Light Truck as described in the attached specification.
4 x 2 light truck minimum 4, 500kg gvm, 4 x 2 cab chassis truck, steel tipping body with 2way tailgate, drop down sides, rope rails, minimum 650mm gap between cab and tipping body for storage box, 110 kw diesel engine automatic transmission, sideboards when unladen must be less than **** from top of sideboard to, the ground flat floor, tailgate to swing towards kerb side with spring load shotbolt tipping body headboard height approx. 600mm high, underbody telescopic hoist to be fitted with capacity to lift the fully laden tipping body. all equipment for operation to be included, fitted safety stand, clearence and taillights fitted with l. e. d lights, full specs of body to be included with quote, tow kit pintle hook, 50mm tow ball coupling, provisions for safety chains, engineer compliance plate fitted to tow bar assembly, heavy duty round trailer plug fitted, electric trailer brake controller, spare tyre mounted and fitted to truck chassis, cab to include full instrumentation, air conditioning, heart demis
AI helper
The council is seeking quotations for a 4 x 2 light truck. The price submitted will include delivery to Cootamundragundagai Regional Councils depot William Street, Gundagai. Include the provision of the vehicles first scheduled service. All vehicles are to arrive with NSW registration for a period of 12 months and include registration paperwork to demonstrate appropriate registration. Reimbursement of the cost of registration will be made separately therefore the cost of registration should be invoiced independently. Council will supply the compulsory third party insurance and the registration letter of authority to the successful supplier. Details of all warranties are to be submitted with response. All terms and conditions must be clearly stated and include detail of any nongenuine equipment fitted along with any extended warranty that may be available. The anticipated delivery timeframe is to be clearly shown in the response. The response should clearly set out what if any Australian manufactured components are to be included in the tipper truck and dog trailer offered. Quotations must detail manufacturers name and model number of each item offered quotations must provide detailed manufacture specifications and complete descriptive literature on each item offered responses must be submitted in one pdf document only.
The anticipated delivery timeframe is to be clearly shown in the response.
Details of all warranties are to be submitted with response. All terms and conditions must be clearly stated and include detail of any nongenuine equipment fitted along with any extended warranty that may be available.
Council will seek to obtain best value for money in any purchasing activity. Council will consider a minimum of the following when evaluating quotations: price operational costs product quality ongoing product support supply and delivery timeframe of quoted items as well as spare parts work health and safety benefits and risks
The respondent must complete all relevant sections. Failure to sign statement below by authorised representative will render bid invalid.
The supplier query cutoff is Thursday 22 January 2026 12:00 am E. South America Standard Time.
Wesley Hill Billiards Room - Roof Replacement - Mount Alexander Shire Council is seeking a suitably qualified and experienced contractor to replace the existing roof along with associated works at the Wesley Hill War Memorial Stadium - Billiards Room. The billiards room is an attached building on the right- hand side of the entrance to the main stadium and is situated at 2- 20 McGarth Street Castlemaine. - Full details of the Scope of Work is detailed within the attached Project Brief.
Wesley Hill Billiards Room Roof Replacement Site establishment and preparation including but not limited to temporary fencing, signage, safety railings and access equipment site protection works, including the protection of billiards tables that are to remain on site a disconnection of all lighting and ceiling fans before asbestos removal b removal and disposal of existing roof sheeting and associated drainage materials, and roof ridge ventilated capping from main room only c replace all roof sheets with similar roof fixings to existing, taking care not to damage the existing structure unnecessarily from main room only installation to be in conformity to asnzs **** part 2 2018 design and installation of sheet roof wall claddingmetal and asnzs **** part 3 2018 plumbing and drainagestormwater drainage d roof ridge ventilation capping is to be replaced with standard ridge capping e replace gutters and downpipes. ensure full gutters and downpipes clear building perimeter to minimise potential for dampness in the
AI helper
The Mount Alexander Shire Council is seeking a contractor to replace the roof of the Wesley Hill War Memorial Stadium Billiards Room. The site visit is mandatory. Quotations close at 2:00 PM, Tuesday 3 February 2026. Payment terms are 30 days after the superintendent of works has approved works for payment. The general conditions of contract are the Maddocks Minor Works Contract. The price submitted must include all GST payable under the contract. Evaluation of submissions will be carried out in accordance with councils policies and procedures. Quotes will be evaluated on the following criteria, but not limited to: risk management, response to scope of works, experience qualifications, business capacity and quality management, and sustainability. The contractor must comply with all ohs laws. The contractor is responsible for the care of the works from the execution date until 4:00pm on the date of practical completion. The contractor must provide the security to the principal prior to commencement of the works on the site. The contractor must provide the security to the principal prior to commencement of the works on the site. The contractor must effect and maintain the following insurance policies for the duration of the works: a public liability insurance policy, contract works insurance, and workers compensation insurance. The contractor must give the principal a notice of delay within 5 business days of the date it became aware, or a competent contractor would have become aware whichever is the earlier of such delay. The contractor must carry out rectification of defects at times and in a manner causing as little inconvenience to the occupants or users of the works as is reasonably possible. The principal may at any time before the date of practical completion direct the contractor to carry out a variation. The contractor may only submit payment claims on or before the time for submission of payment claims stated in the covering page. The contractor must make an adjudication application to an authorised nominating authority. The principal may suspend the carrying out of the works or part of the works by issuing a written notice to the contractor. The principal may terminate the contract by giving written notice to the contractor.
The bid notice states construction practical completion is expected by 30 may 2026 to meet council commitments.
The bid notice states payment terms are 30 days after superintendent of works has approved works for payment.
The bid notice states Evaluation of rfq submissions will be carried out in accordance with councils policies and procedures. Quotes will be evaluated on the following criteria, but not limited to: stage one qualitative assessment of a weighted score totalling 100 1. 1 risk management ohs system pass fail insurance coverage to meet the requirements of this tender 1. 2 response to scope of works the scope of works is a clear, complete and accurate statement of the description and technical requirements of a project. this evaluation criterion will include but is not limited to consideration of: project methodology and preliminary program how do you intend to meet the requirements of the scope of worksproject brief have all response schedules been completed in full and relevant supporting information provided. 1. 3 experience qualifications previous experience delivering similar projects of this size and scope relevant previous experience and qualifications of key personnel previous local government experience inc. working with mount alexander shire council 1. 4 business capacity and quality management quality management business capacity 1. 5 sustainability tenderers are to complete sustainability procurement schedule as part of their tender submission and provide details about how they intend to address the following sustainability principles in their submission: aboriginal and torres strait islander environmental local content economic benefit social benefits whenever it is practical to achieve value for money page 5 stage two quantitative assessment 2. 1 cost to council direct indirect direct the quoted price submitted for the provision of goods, services or works. indirect all costs associated with management and contract supervision, including risk management and contract management, where deficiencies are identified within tender submissions. such adjustments will be considered during evaluation noting the likelihood for council to bear such indirect costs during the project. rates for variations will also be considered. evaluation of price direct and indirect against weighted score calculated as: vfm tendered price ÷ stage one score. to be the successful tenderer, the aim is to have a lower price and a higher stage one score, meaning the lowest result is the best value for money.
The bid notice states mount alexander shire council is seeking a suitably qualified and experienced contractor toreplace the existing roof along with associated works at the wesley hill war memorial stadium billiards room.
The bid notice states if the contractor fails to reach practical completion by the date for practical completion, thecontractor will be immediately indebted to the principal for liquidated damages at the rate stated inthe covering page for every day after the date for practical completion to and including the date ofpractical completion or the date that the contract is terminated, whichever first occurs.
The bid notice states he submitter shall become acquainted with the nature and extent of the quotation requirements making examinations, investigations and enquiries relevant to its obligations under this quote, and to be aware of risks, costs and contingencies associated with the scope of works. if the submitter has any doubt as to the meaning or completeness of any portion of the quotation documents council shall supply to the submitter information as requested in writing only. there will be an opportunity for tenderers to visit the site with a masc representative on the following date: date: tuesday 27 january 2026 time: 10: 00am location: 220 mcgarth street, castlemaine rsvp: ***@***. *. * by 12 noon, monday 26 january 2026 please note the site visit is a mandatory requirement.
The bid notice states supplier query cutoff monday 02 february 2026 12: 00 am e. south america standard time
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
90% recommend BidHits Australia (1058 real users, 08/06/2026).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
We selected helpful reviews from real users. Order may change periodically.
It is complete and optimal, it improves my time.
R. de L. Cruz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
A complete, easy-to-use system. Support from calm, patient, and clear-teaching professionals.
W. M. Da Silva
It encompasses all portals in one place.
G. Ferrea
Excellent platform to help promote and expand the reach of your work.
C. Merino
Sending job opportunities via email is very good. Their information sources are rich in opportunities. The ease of use and advanced search options also make the work easier. The great advantage is the well-organized compilation that facilitates the search for opportunities.
V. De Folga
Efficiency in search times.
R. Chavez
I liked it — very easy to navigate. It’s the best one I’ve found.
T. Brasil
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
The platform is very user-friendly.
N. Lobato
I’m absolutely delighted with the system’s performance so far. This software has exceeded all my expectations, ensuring that no crucial keyword, such as “cathodic protection” and others related, goes unnoticed. Its precision and efficiency are remarkable, providing extra peace of mind in our operations. I’m truly impressed by its effectiveness.
BidHits Australia helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00/month. All plans include the same features, and longer terms reduce the pro-rata cost. You can start with the free trial with no auto-charge.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits Australia shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits Australia now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1058 active users, conducted through 08/06/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
