Tenders are invited for the Richmond Oval - New Changeroom Building & Remediation Works to Grandstand. Compliance with the Council's online tool for managing contractors' Work Health and Safety (WHS) systems is mandatory. Submissions failing to comply will not be considered. The contract works are scheduled for commencement in October 2026, with a completion date no later than the end of January 2028. A 12-month defects liability period applies. Security required is 5% of the contract sum. Working hours are Monday to Friday, 7:30 am to 4:30 pm. Payment is based on monthly claims, with assessment and payment within specified business days. The contract sum is a fixed lump sum price, exclusive of GST. Dispute resolution involves negotiation, mediation, and arbitration.
The date for completion is no later than the end of January 2028. date for completion: the tenderer to provide program with shortest practical completion time, with a completion date no later than end january 2028
The Council must pay the assessed amount including GST but less any retention sum within 30 days of the end of the month in which the assessment is issued. he council must pay the assessed amount including payment for gst but less any retention sum within 30 days of the end of the month in which the assessment is issued.
The contractor warrants that it has entered into the agreement with full knowledge of existing conditions and has not relied on council advice regarding them. he contractor warrants to the council that is has entered into this agreement with full knowledge of the existing conditions, has not relied on any advice or statements by the council regarding the existing conditions and has taken appropriate advice in respect of the existing conditions or chosen not to seek or receive such advice.
Tenderers must be suitably qualified. invites tenders from tenderers for the provision of the richmond oval - new changeroom building & remediation works to grandstand, ( the works).
If the contractor fails to remedy a defect within the specified time, the Council may rectify the defect at the contractor's cost. if a defect is not rectified within the time specified in the defects notice, the council may rectify the defect at the contractors cost, without prejudice to any other rights that the council has against the contractor in respect of that defect.
Failure to comply with the Council's online tool for managing contractors' WHS systems will result in a non-conforming submission and will not be considered during the evaluation process. failure to comply with this requirement will result in a nonconforming submission, and such submissions will not be considered during the evaluation process.
