Bed Mat Tenders

Completion of all components of the works, including commissioning, is required by 24 June 2027. completion of all components of the works, including commissioning, is required by 24 june 2027

Progress claims may be submitted for completed works, with payments up to 80% of the contract sum. The remaining 20% becomes payable upon completion and acceptance of required documentation. council will make payments for completed works up to a maximum of 80 of the contract sum until the works are completed

The contractor must provide 12 months warranty on all workmanship from the date of practical completion inspection. the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection

Contractors must be suitably qualified, experienced and resourced, with necessary WHS systems. goondiwindi regional council invites quotations from suitably qualified, experienced and resourced contractors

Failure to maintain progress may result in liquidated damages or other contractual remedies. failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages

There is no mandatory site visit, but requests for a site visit during the tender period are welcome. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome

Any form of canvassing or direct contact with council employees, councillors, or consultants is strictly prohibited and will result in automatic disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process

Completion of all components of the works, including commissioning, is required by 24 June 2027. Respondents must provide a schedule of works with their submission indicating estimated delivery timeframes.

Council will make payments for completed works up to a maximum of 80% of the contract sum until the works are completed. The remaining 20% becomes payable upon completion and submission of required documentation.

The contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection. The contractor must respond to requests for failure in workmanship within 3 business days.

Submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor WHS systems, availability, and local contractor.

Contractors must be suitably qualified, experienced and resourced. They must complete the Contractor WHS Questionnaire (Attachment B) and provide details of relevant experience on similar projects completed within the last 5 years in Australia.

Failure to maintain progress in accordance with the approved project schedule may constitute a breach of contract and may result in the application of liquidated damages or other applicable contractual remedies.

There is no mandatory site visit for these works but requests for a site visit during the tender period are welcome. Requests are to be submitted via the vendor panel question portal.

All enquiries and communication regarding this tender must be submitted via the vendor panel question portal. The supplier query cutoff is Friday 30 October 2026.

Any form of canvassing or direct contact with council employees, councillors, or consultants is strictly prohibited during the tender process. Any breach will result in automatic disqualification from the contracting process.

Completion of all works, including commissioning, is required by 24 June 2027. As stated: completion of all components of the works, including commissioning, is required by 24 june 2027.

Progress claims may be submitted for completed works, with payments up to 80% of the contract sum. The remaining 20% becomes payable upon completion and acceptance of required documentation. As stated: council will make payments for completed works up to a maximum of 80 of the contract sum until the works are completed.

The contractor must provide a 12-month warranty on all workmanship from the date of practical completion. As stated: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Submissions will be assessed on tendered prices, past performance, technical expertise methodology, contractor WHS systems, availability, and local contractor status. As stated: submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

Contractors must be suitably qualified, experienced, and resourced, with necessary skills and systems to manage safety. As stated: goondiwindi regional council invites quotations from suitably qualified, experienced and resourced contractors for the supply and construction of the sewer rising main.

Failure to maintain progress may result in liquidated damages or other contractual remedies. As stated: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.

There is no mandatory site visit, but requests for a site visit during the tender period are welcome. As stated: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

All enquiries and communication regarding this tender must be submitted via the vendor panel question portal. As stated: all enquiries and communication regarding this tender must be submitted via the vendor panel question portal.

Any canvassing or direct contact with council employees, councillors, or consultants is strictly prohibited and will result in automatic disqualification. As stated: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.