2026/287 Koorlong Avenue and Fourteenth Street Swale Reconstruction - Mildura Rural City Council is seeking Tender responses from suitably qualified individuals and organisations to provide civil construction and electrical works, including the removal and disposal of an existing culvert; supply and installation of a 225mm culvert; upgrade of the existing electrical switchboard and pump; construction of 4. 5m and 6m wide swales; and post- project site clean- up with reinstatement of disturbed areas and rep
AI helper
The tender is for civil construction and electrical works. Submissions must be fully received by the closing time as late submissions will not be accepted. Council is not bound to accept the lowest priced tender or all or any part of a tender and reserves the right to conduct the request for tender process and select the successful respondents as it sees fit. All responses must be made by online submission.
The bid notice states a date for practical 30 june 2026 completion.
The bid notice states defects liability period 12 months.
The bid notice states a site inspection with council is available on request via the forum. inspections are recommended however not mandatory.
The bid notice states supplier query cutoff friday 27 february 2026 12: 00 am e. south america standard time.
**** Education Services - Waste and Resource Management - Sunshine Coast Council s Education Services - Waste and Resource Management Contract supports Council s vision to be Australia s most sustainable region by promoting best practice waste disposal, resource recovery, and positive behaviour change across the Sunshine Coast Local Government Area ( LGA). The services align with the Sunshine Coast Resource Recovery Strategy 2023 and broader State and Federal waste policy priorities, including implementa
AI helper
The tender is for education services waste and resource management. The closing date for tenders is 26 March 2026. The contract commences on 11 July 2026 and expires 10 July 2028, with two extension options.
The bid notice states that the contract commences on 11 July 2026 and expires 10 July 2028, with two 2 further extension options, each of up to 12 months, at councils sole discretion.
The evaluation criteria and weightings are: capability and experience 20, methodology 25, social and economic factors 20, price 35.
Clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
**** - EOI - Badu Island - Modular/prefabricated housing solutions - Torres Strait Island Regional Council ( TSIRC) invites Expressions of Interest from suitably qualified Respondents for the building/manufacture, transport, delivery, and installation of modular homes to remote outer island communities within the Torres Strait Island Region, as described in more detail in Part 4 - Scope. This EOI seeks to identify and shortlist proponents with demonstrated capability in delivering full turnkey modular/
building, manufacture, transport, delivery, and installation of modular homes modular prefabricated housing supply predelivery site works mainland and remote logistics and transport installation and commissioning post delivery site works
AI helper
The tender is for the building, manufacture, transport, delivery, and installation of modular homes to remote outer island communities. Expressions of interest must be submitted through VendorPanel by March 11, 2026. Complaints regarding the procurement process should be directed to the Manager, Procurement Contracts via email. There will be no formal tender briefing or site visit at this stage.
The evaluation criteria include relevant experience, manufacturing capacity, and proposed delivery methodology. Evaluation criteria weighting optional relevant experience modular prefabricated housing 30 relevant experience remote access works 20 manufacturing capacity and program 20 proposed delivery and installation methodology 30
There will be no formal tender briefing or site visit at this stage. here will be no formal tender briefing or site visit at this stage. no
Communications regarding the procurement process must be submitted through the forum on respondents: VendorPanel no later than 7 calendar days prior to the time stated in item 4. communications by communications regarding the procurement process must be submitted through the forum on respondents: vendorpanel no later than 7 calendar days prior to the time stated in item 4.
FORWARD PROCUREMENT NOTIFICATION ADVICE ONLY- Targeted Refresh invite to Market & Social Research PSP - FORWARD PROCUREMENT NOTICE - ADVICE ONLY - THIS NOTICE DOES NOT CONTAIN ANY DOCUMENTS Market and Social Research Panel Opportunity This Forward Procurement Notice is to advise Queensland Government Procurement, Department of Housing and Public Works ( HPW) intends to approach the market via an Invitation to Apply ( ITA) process as part of a targeted refresh to the Whole- of Government Preferred Supply Pan
Market and Social Research Panel Opportunity
AI helper
This is a forward procurement notice for a targeted refresh of the Queensland Government's preferred supplier panel for market and social research services (****). The Invitation to Apply (ITA) is expected to be released in early March 2026 via the Queensland Procurement Solution. Suppliers must have an ABN, be registered for GST, and meet insurance requirements. The notice does not contain any documents, and no questions should be submitted at this time. Further information will be provided in a separate notice.
The bid notice states that suppliers must have an australian business number abn must be registered for gst or australian company number acn where applicable are insured for, or are willing to obtain, public liability for at least 10 million are insured for, or are willing to obtain, professional indemnity for at least 5 million are insured for workers compensation as required by law maintain financial viability and have the financial capability to meet their obligations under the psp are capable of presenting a topic or case study within 48 hours in response to a written request are able to meet contractual key performance indicators.
**** - Albany Botanic Walkway - Please refer to the Request for Tender documentation and associated attachments
Boardwalk footings, fabrication, supply and construction of the boardwalk with level sections, stepped sections and ramp sections including post handrails and balustrade handrails where required, as well as inground footings or rockanchor footings as required.
AI helper
The tender is for the construction of a boardwalk. The closing date for the tender is March 18, 2026. A site inspection is scheduled for February 27, 2026, and attendance must be confirmed by February 25, 2026. The contractor must provide a construction program within five days of contract award. The principal requires early notification if a milestone is unlikely to be achieved by the due date. The offer must be lodged by the deadline. The offer is to be submitted via VendorPanel Public Tenders or placed in a sealed envelope. The principal may reject any alternative offer as invalid. All offers shall remain valid for a minimum period of ninety days from the deadline. The contract shall be governed by the laws of the state of Western Australia. The contractor and its subcontractors will be required to effect and submit copies of certificates of currency for insurances. If work under the contract does not reach practical completion by the date specified, liquidated damages of $500 per day will apply. The principal may deduct 5% from each payment claim as security for the performance of the contractor's obligations under the contract. The successful contractor shall provide the principals representative with one full set of approved design drawings with any amendments marked in red and the surveyor shall also supply as constructed information to the city of albany in the current albany spatial data specification asds format within two weeks of practical completion. The contractor shall ensure that all records relevant to or created in the course of this contract are held in a safe and secure manner. Contractors shall state in their quotation the period of warranty and guarantee conditions that apply against defects for the goods offered, together with any aftersales services provided.
The indicative construction period is 20 weeks. Construction period 20 weeks
Contractors shall state in their quotation the period of warranty and guarantee conditions that apply against defects for the goods offered, together with any aftersales services provided.
The principal has adopted a best value for money approach to this request. he principal has adopted a best value for money approach to this request.
Offers that do not contain all information requested as per selection criteria will be excluded from evaluation. Offers that do not contain all information requested as per selection criteria will be excluded from evaluation.
If work under the contract does not reach practical completion by the date specified, liquidated damages of 500 per day will apply. if work under the contract does not reach practical completion by the date specified or an amended date if an extension of time is granted by the principal, liquidated damages of 500 per day will apply.
Tenderers are requested to attend a site inspection on friday 27 february 2026 at 11: 00am. enderers are requested to attend a site inspection on friday 27 february 2026 at 11: 00am.
The cut off for queries is 2. 00pm on11 march 2026 awst in order give all tenderers sufficient time to address additional information. he cut off for queries is 2. 00pm on11 march 2026 awst in order give all tenderers sufficient time to address additional information.
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Start your free trial and receive email alerts
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/territories, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits Australia (1001 real users, 27/02/2026).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
We selected the most helpful reviews from real users. Order may change periodically.
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Efficiency in search times.
R. Chavez
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
Easy to find the bids.
R. M. David
Excellent platform to help promote and expand the reach of your work.
C. Merino
With the chosen keywords, I can find many tenders of interest! I learn about new notices well in advance, giving me enough time to get organized to participate.
D. Comaq
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
It helps me identify areas of opportunity and find tenders related to my work area.
I. J. R. Beltran
It is complete and optimal, it improves my time.
R. de L. Cruz
The search tool really works and satisfactorily meets our needs.
D. L. Cairuga
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
BidHits Australia is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals every day at the Commonwealth, state/territory and local council levels. Tenders are added to the system as soon as they are published on the source portal.
Plans start at A$ 65.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia. Start by adding a few keywords. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits Australia now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1001 active users, conducted through 27/02/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
