Fence Repair Tenders

The contract specifies a date for practical completion, which is to be filled in on the day of 20, or a period of time for practical completion in days or weeks after the date of acceptance of tender.

The contract states that the principal must pay the contractor in accordance with the provisions of the contract. Annexure Part B defines a 'payment period' as 15 business days for a building contract or 25 business days otherwise, after the progress claim or final payment claim is given to the principal. The contractor must provide a tax invoice with each progress claim.

The contract includes provisions for design work where the contractor warrants that the design will be in accordance with the contract requirements and that personnel engaged are suitably qualified and experienced. The contractor also warrants that the design documents will not infringe any intellectual property rights.

The contract requires the contractor to ensure that personnel engaged in design obligations are suitably qualified and experienced. Annexure Part D includes a contractor's statutory declaration that they remain able to pay their debts as and when they become due and payable.

The contract includes provisions for liquidated damages at a rate per day, with a limit or percentage of the contract sum. It also details delay damages at a rate per day as reasonably assessed by the principal.

The contract specifies a time for giving access to the site to the contractor, which is within days after the date of acceptance of tender, with a default of 14 days if not stated. If a part of the works is to be designed by the contractor, the principal shall give the contractor access to the site sufficient to enable the contractor to commence and carry out the contractor's design obligations.

The definition of 'contractor's design documents' includes samples, models, patterns and the like required by the contract to be created by the contractor.

The bid notice states that contractors must hold appropriate public liability insurance, relevant licences, and comply with whs requirements.

The deadline for this request is as per the closing datetime published on vendorpanel.

The contractor shall obtain and ensure that the principal will have the benefit of all warranties specified in the contract including the following items of work, materials or equipment: 1. fence panels infill materials o durability and corrosion resistance warranty 2. fence posts and rails o warranty for structural integrity and corrosion resistance 3. foundations and footings o contractor workmanship warranty for footings, embedment depth and concrete strength. 4. gates and gate hardware o manufacturers warranty on hinges, latches, locks. o contractor workmanship warranty on installation and alignment. 5. coatings finishes o powdercoat warranty e. g. , against chipping, peeling, uv fading. 6. fasteners and fixings o warranty against corrosion e. g. , stainless or galvanised screwsbolts. 7. overall workmanship warranty o typical defects liability period e. g. , 12 months covering alignment, installation defects, and general construction quality.

The contract may be awarded to a sole respondent who best demonstrates the ability to provide quality products andor services at a competitive price. Price will be assessed together with qualitative and compliance criteria to determine the most advantageous outcome to the principal.

The city of bunbury invites suitably qualified contractors to submit a quotation for the removal and replacement of the playing field fence located at the carey park football club home ground, kelly park 45 wisbey street, carey park.

In the event of the contractor failing in any manner to carry out the contract to the principals satisfaction, the principal may forthwith terminate the contract by written notice to the contractor.

There is no briefing or site inspection for this request, however a site visit is highly recommended with access to the site being available at any time.

Written clarifications must be made using ask a question on vendorpanel and may be subject to an addendum to this request. No requests for information or clarification of the request will be accepted later than three 3 days prior to the deadline of this request.