Electrical works package for Texas WWTP upgrade. Supply, installation, testing, commissioning, closeout. Single site at Texas, QLD. Tender closes 4 Nov 2026 4pm EST. Lump sum contract, 90?day validity, completion by 17 Dec 2027. Evaluation on price, past performance, technical expertise, WHS, availability, local contractor. No mandatory site visit.
Completion by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027.
12 months warranty on workmanship. contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
Price, past performance, technical expertise, WHS, availability, local contractor. submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.
Contractor must have necessary skills and expertise. the necessary skills and expertise to be able to competently supply the scope of works.
No mandatory site visit. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
4 November 2026 4pm EST. tender closing openingsubmissions shall be lodged on or before the closing time of 4pm est, wednesday 4th november 2026.
Direct contact outside approved channel leads to disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
