ACMI Cinema Lighting Renewal - ACMI is seeking submissions from suitably qualified contractors to supply, install and commission a full LED lighting, digital control and lighting bar renewal across Cinema 1 and Cinema 2 at ACMI, Federation Square. The works will replace end- of- life lighting, control, dimming, cabling, hoist and bar management systems originally installed when the building opened in 2002. The scope includes new LED house, profile and Fresnel- type fixtures across both cinemas, digital ligh
LED lighting, digital control and lighting bar renewal Full LED lighting, digital control, and lighting bar renewal across Cinema 1 and Cinema 2 at ACMI, Federation Square. This includes new LED house, profile, and Fresnel- type fixtures, digital lighting control with staff- friendly wall panels, bio box lighting conversion to DALI control, replacement chain hoists and energy chains across six lighting bars, rebuilt dimmer cupboard infrastructure, new power, DMX and data cabling, emergency lighting works, testing, commissioning, certification, and training.
AI helper
ACMI is seeking qualified contractors to supply, install, and commission a full LED lighting, digital control, and lighting bar renewal for Cinema 1 and Cinema 2. The works must be delivered in a live public venue around programming commitments, with ACMI intending to sequence the works during a reduced programming period within a December to January delivery window. Submissions must detail a clear methodology for access, working at height, safety compliance, and coordination with ACMI staff. The tender closes on August 23, 2026, at 2:00 pm.
ACMI intends to sequence the works during reduced programming period within a December to January delivery window.
Submissions should demonstrate a clear methodology for access, working at height, protection of fixed seating and finishes, safety compliance, defect rectification and coordination with acmi staff and site requirements.
Forum posts cannot be posted after 20 august 2026 10:20 am.
The use of the forum for supplier selfpromotion is unacceptable and may result in the supplier having their account suspended.
ITT242 Civil Construction - Caloundra Transport Corridor Upgrade - Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade ( CTCU). The CTCU is made up of two sections - Section 1 and Section 2 with works under the Contract to incorporate, but not be limited to: Separable Portion 1 - Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way - Section 1 and 2: Section 1 ( Works Package A) Duplicating existing traffic lanes to provide two lanes in e
Civil construction of the Caloundra Transport Corridor Upgrade ( CTCU) Separable Portion 1: Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way ( Section 1 and 2). Section 1 ( Works Package A): Duplicating existing traffic+signal+government+procurement+opportunities+99724&idLj=94E3BX" style="text-decoration: underline; color: var(--color_text_heading); text-underline-offset: 2px;" title="Traffic Signal Tenders" >traffic lanes, building a two- way cycle track and pedestrian pathways ( Works Package D), upgrading intersections to traffic signals, changes to traffic movements, installing new street lighting and landscaping. Section 2 ( Works Package B): Arthur Street to Industrial Avenue Nicklin Way, Third Avenue extension, connection of Industrial Avenue to Nicklin Way, upgrading intersection of Arthur Street/Third Avenue, installing new street lighting and landscaping. Works Package D: CTCU Section 1 cycle track infrastructure. Separable Portion 2: Arthur Street drainage upgrade works ( Works Package C): New box culvert along Arthur Street, new box culverts crossing Arthur Street.
AI helper
Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade (CTCU). The project involves two sections and multiple works packages, including road duplication, cycle tracks, pedestrian pathways, intersection upgrades, drainage, street lighting, and landscaping. Respondents must price all separable portions. DTM R prequalification (R3, A3, F50) is mandatory. A contract is anticipated to be awarded in May/June 2026, with practical completion by December 2027. An information session will be held on 19 March 2026 at 10 am. Tenders close at 12 noon on 12 May 2026. All enquiries must be in writing via email to ***@***. *. * submission is required through VendorPanel Marketplace.
Tenders will be accepted until 12 noon on 12 May 2026.
The evaluation criteria are: Capability and Experience (15%), Methodology (30%), Social and Economic Factors (15%), and Price (40%).
The contractor must have and maintain DTM R prequalification to level R3, A3, and F50 for the life of the contract.
An information session will be held onsite on 19 March 2026 at 10 am. Respondents are encouraged to attend.
Clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
Direct contact with any elected member of council or local government employee regarding any part of this tender, other than those listed in schedule 1 item 5, is prohibited. Any prohibited contact may result in disqualification.
Real Festival 2026_ Av, Stage and Lighting - Council is seeking a suitably qualified and experienced supplier to provide event AV, Staging and Lighting for the Flagship event, REAL Festival. - Please refer to scope for full detail.
Event AV, Staging and Lighting Provision of marquees, tables, chairs, staging, fencing, equipment, and associated installation and packdown services for Real Festival 2026 and 2027. Includes decorative truss uprights, decorative lighting, LED colour wash, ambient lighting, feature lighting, coloured LED uplights, festoon lighting, illuminated works ( neons/light sculptures), acoustic performance stage with sound system and lighting, power runs for food stalls/trucks, ambient music provision, market zone/games/DJ stage with lighting and power, and arcade area with structure, DJ decks, riser, and audio equipment. Also includes advice on required plant ( generators, distribution boxes, cabling) and staffing/labour for installation and packdown.
AI helper
Penrith City Council is seeking a supplier for event AV, staging, and lighting for the Real Festival in 2026 and 2027. The scope includes marquees, staging, lighting, sound systems, power, and installation/packdown services. Suppliers must submit a rates card for 2026 and an indicative estimate for 2027. The contract will be for two years, subject to performance. The event dates for 2026 are September **** is scheduled from September 7-10, with bump-out by September 16, 2025. The supplier must provide after-hours support and remove all waste generated during installation.
Bump in is scheduled to commence on Monday 7 September 2026, with all infrastructure to be removed by no later than 5pm Tuesday 16 September 2025. all infrastructure to be removed by no later than 5pm tuesday 16 september 2025
The buyer is seeking a suitably qualified and experienced supplier. council is seeking a suitably qualified and experienced supplier to provide event av, staging and lighting
The document mentions draft site maps and that event elements are subject to change and require a site recce to confirm requirements, suggesting a site visit may be necessary. event elements are subject to change and require a site recce to confirm requirements
The supplier query cutoff is Thursday 04 June 2026 11:00 pm E. South America Standard Time. supplier query cutoff thursday 04 june 2026 11: 00 pm e. south america standard time
ITT242 Civil Construction - Caloundra Transport Corridor Upgrade - Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade ( CTCU). The CTCU is made up of two sections - Section 1 and Section 2 with works under the Contract to incorporate, but not be limited to: Separable Portion 1 - Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way - Section 1 and 2: Section 1 ( Works Package A) Duplicating existing traffic lanes to provide two lanes in e
Civil construction of the Caloundra Transport Corridor Upgrade ( CTCU) Separable Portion 1: Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way ( Section 1 and 2). Section 1 ( Works Package A): Duplicating existing traffic lanes, building a two- way cycle track and pedestrian pathways ( Works Package D). Upgrading intersections to traffic signals. Changes to traffic movements. Installing new street lighting and landscaping. Section 2 ( Works Package B): Arthur Street to Industrial Avenue Nicklin Way, Third Avenue Extension, connection of Industrial Avenue to Nicklin Way, upgrading Arthur Street/Third Avenue intersection, installing new street lighting and landscaping. Package D: CTCU Section 1 cycle track infrastructure. Separable Portion 2: Arthur Street drainage upgrade works ( Works Package C): New box culvert along Arthur Street, new box culverts crossing Arthur Street.
AI helper
Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade (CTCU). The project involves two sections and multiple works packages, including road duplication, cycle tracks, pedestrian pathways, intersection upgrades, drainage, street lighting, and landscaping. Respondents must price all separable portions. DTM R prequalification (R3, A3, F50) is required. The contract is anticipated to be awarded in May-June 2026, with practical completion by December 2027. An information session will be held on 19 March 2026 at 10 am. Tenders close at 12 noon on 12 May 2026 and must be submitted electronically via VendorPanel. Evaluation criteria include capability, methodology, social/economic factors, and price.
Tenders must be submitted electronically through VendorPanel Marketplace prior to the closing date: 12noon, 12 May 2026.
The evaluation criteria are: Capability and Experience (15%), Methodology (30%), Social and Economic Factors (15%), and Price (40%).
The contractor must have and maintain DTM R prequalification to prequalification level R3, A3, and F50 to be eligible to provide a tender response.
An information session will be held onsite on 19 March 2026 at 10am. Respondents are encouraged to attend to familiarise themselves with the site.
Clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
Direct contact with any elected member of council or local government employee regarding any part of this tender, other than those listed in schedule 1 item 5, is prohibited. Any prohibited contact may result in disqualification.
ITT242 Civil Construction - Caloundra Transport Corridor Upgrade - Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade ( CTCU). The CTCU is made up of two sections - Section 1 and Section 2 with works under the Contract to incorporate, but not be limited to: Separable Portion 1 - Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way - Section 1 and 2: Section 1 ( Works Package A) Duplicating existing traffic lanes to provide two lanes in e
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
It encompasses all portals in one place.
G. Ferrea
Good information. All the information is very good!
J. A. Tellez
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
It helps me identify areas of opportunity and find tenders related to my work area.
I. J. R. Beltran
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The platform is very user-friendly.
N. Lobato
Excellent information. Just what I was looking for.
L. H. Borrelli
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
It is complete and optimal, it improves my time.
R. de L. Cruz
The idea of ​​using a keyword and sending the information by email is very good.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 32.50 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1107 active users, conducted through 21/10/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
