Pipe Testing Tenders

Completion of all components of the works, including commissioning, is required by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site, including labour, plant, and installation, or for materials delivered to site. progress claims may be submitted for works fully executed on site

The contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection. the contractor is responsible to provide 12 months warranty on all workmanship

Contractors must have necessary skills and expertise, and complete the Contractor WHS Questionnaire. the respondent is responsible for and warrants that it has: . . . the necessary skills and expertise to be able to competently supply the scope of works.

Failure to maintain progress may result in liquidated damages. failure to maintain progress in accordance with the approved project schedule . . . may result in the application of liquidated damages

There is no mandatory site visit, but requests are welcome via the Vendor Panel question portal. there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

Any form of canvassing or direct contact with council employees, councillors, or consultants is strictly prohibited and will result in automatic disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification

Completion of all works including commissioning is required by 17 December 2027. The document states: completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site or materials delivered to site. The document states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.

The contractor provides 12 months warranty on all workmanship from practical completion. The document states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Contractors must have necessary skills and expertise. The document states: the contractor warrants that it has the necessary skills and expertise to be able to competently supply the scope of works.

Failure to maintain progress may result in liquidated damages. The document states: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.

No mandatory site visit, but requests are welcome. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Direct contact with council employees or councillors results in automatic disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

Projects must be completed before May 2028. The tender closes on 11 December 2026. design, approvals, construction, testing, commissioning, and handover of two separable stormwater drainage infrastructure projects within baxter road and botany lane, mascot before may 2028.

Site visit is scheduled. The notice states: site visit: date: wednesday 28 october 2026 time: 9: 00am location: whyanbeel water treatment plant end of karnak road maximum number of attendees per tenderer: 2.

The evaluation criteria include professional competence 30, methodology and program 30, and financial 40, with overall value for money as the final assessment.

Mandatory requirements include experience with delivering projects in state government facilities minimum 5 years and experience with delivering projects in live operating environments.

The briefing session is mandatory: attendance at the briefing session is mandatory as noted in clause 2. 3 of part b. 2 victorian government requirements.

Failure to attend the mandatory briefing session may lead to disqualification: if an invitee fails to attend a mandatory briefing session, the organisation may disqualify the invitee.