Pavement Construction Tenders

The works are to be completed by 30 September 2026. The works are to be completed by 30 september 2026.

The evaluation criteria include price (50%), experience, past performance, capability, demonstrated understanding, resources, quality, environmental, safety, other management processes, and local content. Evaluation criteria Evaluation criteria Weighting Optional Price 50% Experience Past performance capability 10% Demonstrated understanding resources 15% Quality, environmental, safety other management processes 15% Local content 10%

Contractors must be suitably qualified and experienced. invites suitably qualified and experienced contractors

A mandatory tender briefing and site inspection will be held on 14th May 2026 at 09:00 am at 62 Valentine Plains Road, Biloela QLD **** rsvp tender briefing: 14th of may 2026 **** am, 62 valentine plains road, biloela qld ****

Supplier queries must be submitted no later than 5 calendar days prior to the tender submission deadline. communications regarding the procurement process must be submitted to vendor panel no later than 5 calendar days prior to the time stated in item 4

The submission deadline for tenders is 2pm WST on Monday, June 8, 2026. Tenders must be lodged via the VendorPanel portal.

Invoices for payment shall be submitted to the Principal's representative at the end of each month. Payment will be made within 20 business days of an accepted claim/invoice. This is a fixed price contract, with provisions for escalation related to fuel costs.

The defects liability period is 12 months.

Tenders will be assessed against compliance criteria, qualitative criteria, and a priced attribute. The submission with the highest aggregate score, representing the best value for money, will be considered first for award.

Mandatory requirements include demonstrated experience and competence in similar services, senior-level project management, contract compliance in infrastructure projects, and the capability to mobilize and demobilize a works crew for remote operations. Compliance with legislative requirements, especially indigenous heritage, is also mandatory.

Liquidated damages and bonus for early practical completion are not specified (rate nil).

The clarification deadline is 2pm WST on Monday, June 1, 2026. Queries sought after this deadline will not be responded to.

Tenders may be rejected if not submitted before the deadline, not submitted at the specified place, fail to comply with other requirements, or if the offer form is not completed and signed with all required attachments. Canvassing officials will also result in rejection.

The tender closes on Wednesday, 24 June 2026 at 01:00 am E. South America Standard Time.

By lodging a response, the respondent warrants that all information provided is accurate and that they hold all necessary competencies, licenses, and authorisations required for the scope of work.

Responses will be assessed against evaluation criteria, but not exclusively. The principal may consider information from the response, meetings, referee discussions, past performance, and subjective opinions of evaluators.

Tenderers must be suitably qualified and hold all necessary competencies, licenses, accreditations, certifications, permits, and authorisations required for the scope of work.

Respondents are encouraged to attend any briefing or site inspection identified as mandatory. If no site inspection is identified, respondents must make their own arrangements to inspect the site prior to lodging their response.

The principal may reject responses if the respondent has failed to comply with procurement conditions, breached a warranty, or if the response fails to achieve a satisfactory score against evaluation criteria.