Logs Tenders

Respondents must be registered for GST and state their ABN in their response. The principal may ask for evidence of legal status or capacity to contract. Respondents must be registered for gst and state their abn in their response.

Responses may be excluded if non-conforming, late, incomplete, or if the respondent is bankrupt or subject to a winding up order. The principal may exclude nonconforming responses from the rfx process without further consideration.

Works must be completed by the end of June 2027. The contract is expected to commence November 2026. As stated: this contract is expected to commence november 2026 with works to be completed by the end of june 2027.

The evaluation criteria include proven experience, skilled personnel, project approach, ability to deliver within timeline, project communication, and price. Council seeks the best quality and value for money for the community.

Tenderers must demonstrate experience, commitment and capacity for the delivery of the works and meet mandatory compliance criteria including statutory declaration, compliance with conditions, insurance, ABN registration, and working with children cards.

An optional site inspection is scheduled for 2-3pm Tuesday 15 September 2026 at Watson Park playground, Munro Avenue, Ashburton. Tenderers must preregister with Hillary McLeish by Monday 14 September 2026.

Late submissions will not be accepted. Nonconforming tenders may be rejected. Tenderers engaging in prohibited canvassing may not be considered. Failure to complete required documents may result in rejection.

Quotations must be fully received by the closing date and time. The closing date is 23/10/2026 at 3pm. closing date: **** and closing time: 3pm

The quotation that represents the best value will be selected. these criteria will be used to determine the quotation that represents the best value.

Respondents must be approved suppliers under the NSW whole of government integrated security services contract **** must be on the nsw whole of government integrated security services contract **** to be eligible to tender for this contract.

Clarifications may be sought up to 3 business days prior to the closing date. respondents may, up to 3 business days prior to the closing date and time, seek clarification of any aspect of this rfq

Late quotations will not be accepted. late quotations will not be accepted, except where the integrity and competitiveness of the quotation process has not been compromised

Submissions will be assessed to determine the supplier that shall provide council the best quality and value for money for the community. council may at its discretion also utilise information from any other sources including, but not limited to, its own experience with the supplier, reference checks, to determine the supplier that shall provide council the best quality and value for money for the community.

Tenderers must demonstrate experience, commitment and capacity for the delivery of the works to be performed under the contract. tenderers must demonstrate experience, commitment and capacity for the delivery of the works to be performed under the contract.

An optional site inspection has been scheduled for 23pm tuesday 15 september 2026 to be held at watson park playground munro avenue, ashburton. an optional site inspection has been scheduled for 23pm tuesday 15 september 2026 to be held at watson park playground munro avenue, ashburton

Tenders that fail to comply with any requirement specified in these tender information and conditions of tendering, or which contains any qualification, condition or other indication that the tenderer is not willing to perform the contract in strict accordance with the contract documents, shall be considered to be nonconforming and may be rejected at the discretion of council. any tender failing to comply with any requirement specified in these tender information and conditions of tendering, or which contains any qualification, condition or other indication that the tenderer is not willing to perform the contract in strict accordance with the contract documents, shall be considered to be nonconforming and may be rejected at the discretion of council.

Submissions will be assessed to determine the supplier that shall provide council the best quality and value for money for the community. council may at its discretion also utilise information from any other sources including, but not limited to, its own experience with the supplier, reference checks, to determine the supplier that shall provide council the best quality and value for money for the community.

Tenderers must demonstrate experience, commitment and capacity for the delivery of the works to be performed under the contract. tenderers must demonstrate experience, commitment and capacity for the delivery of the works to be performed under the contract.

An optional site inspection has been scheduled for 23pm tuesday 15 september 2026 to be held at watson park playground munro avenue, ashburton. an optional site inspection has been scheduled for 23pm tuesday 15 september 2026 to be held at watson park playground munro avenue, ashburton

Tenders that do not meet mandatory requirements will not be considered further. suppliers that do not meet the mandatory requirements will not be considered further.