SUPPLY AND DELIVER MEDIUM TIP TRUCK **** - **** kg - Balonne Shire Council invites tenders from suitably qualified respondents for supply and delivery medium tip truck ****- ****kg as described in more detail in Part 5 . IMPORTANT NOTE for Respondents: If you are submitting multiple options or quotes, each variant must be uploaded as a separate, individual submission. Please do not combine multiple quotes into a single upload.
**** Upgrades to Staff Housing 25- 26 - 1 INTRODUCTION The Central Highlands region is in Central Queensland, Australia. This region encompasses an area of around 60, 000 square kilometers, making it just short of the size of Tasmania. It is home to around 30, 000 people who live in the regional centers of Emerald ( approximately 15, 000 people) and twelve other unique communities being Arcadia Valley, Bauhinia, Blackwater, Bluff, Capella, Comet, Dingo, Duaringa, Rolleston, Gemfields, Springsure and Ti
Upgrades to staff housing Internal repainting preparation and repainting of internal walls, ceilings, doors, frames, skirtings, architraves, shelving and cupboards surface preparation including cleaning, sanding, patching and priming protection of existing finishes and final cleandown works indicative quantities include: oapprox. 489m walls oapprox. 255m ceilings oapprox. 240lm skirting boards and oapprox. 10 internal doors. Flooring works removal and disposal of existing carpet and underlay subfloor preparation supply and installation of new carpet and underlay or approved vinyl flooring installation of trims and transitions indicative areas include: oapprox. five 5 bedrooms including robewir areas. Window furnishings removal and replacement of blinds and associated hardware supply and installation of roller blinds and panel glide blinds adjustment and testing of installed systems indicative quantities include: oapprox. sixteen 16 windows and sliding door systems. General protection of existing finishes remo
AI helper
This tender is for upgrades, repairs, and renewals to staff housing properties managed by Central Highlands Regional Council. The works include internal repainting, flooring, and window furnishings, with specific details provided in the scope of works and bill of quantities. The tender is open to qualified and experienced building contractors. Properties are located in Duaringa, Capella, and Blackwater, with some prioritized as vacant and others occupied. Tenderers must verify site conditions prior to pricing, and a 12-month defects liability period will apply. The council reserves the right to award all, part, or none of the works, and pricing should be submitted per property. Compliance with Australian standards, workplace health and safety regulations, and specific council requirements is mandatory. A pre-start meeting and ongoing project meetings will be held. LinkSafe induction and relevant licenses and insurances are required.
The closing time for tenders is Friday, 12th June 2026, at 04:00 am E. South America Standard Time.
Tenderers shall allow for a twelve 12 month defects liability period DLP for each property from the date of practical completion.
Tenders will be evaluated by reference to the sound contracting principles in section 106 of the local government act ****, namely: value for money, open and effective competition, the development of competitive local business and industry, environmental protection, and ethical behaviour and fair dealing.
The principal is seeking a qualified and experienced building contractor to rectify staff housing building defects and modify or renew building components.
Tenderers shall verify all dimensions, quantities, existing conditions and site constraints prior to pricing and commencement of works. No variation claims will be accepted for failure to inspect site conditions.
The supplier query cutoff is Wednesday, 10th June 2026, at 04:00 am E. South America Standard Time.
If a tender response for a tender is not fully completed or does not include all supporting documents and materials required by the conditions of tender or the tender response, the tender may be rejected.
SUPPLY AND DELIVER MEDIUM TIP TRUCK **** - **** kg - Balonne Shire Council invites tenders from suitably qualified respondents for supply and delivery medium tip truck ****- ****kg as described in more detail in Part 5 . IMPORTANT NOTE for Respondents: If you are submitting multiple options or quotes, each variant must be uploaded as a separate, individual submission. Please do not combine multiple quotes into a single upload.
Supply and delivery of a medium tip truck ( ****- ****)
SUPPLY AND DELIVER MEDIUM TIP TRUCK **** - **** kg - Balonne Shire Council invites tenders from suitably qualified respondents for supply and delivery medium tip truck ****- ****kg as described in more detail in Part 5 . IMPORTANT NOTE for Respondents: If you are submitting multiple options or quotes, each variant must be uploaded as a separate, individual submission. Please do not combine multiple quotes into a single upload.
Supply and delivery of a medium tip truck ( ****- ****)
AI helper
Balonne Shire Council is seeking tenders for the supply and delivery of a medium tip truck with a capacity of 4500-6500kg. The truck must comply with Australian standards for ROPS and FOPS, and have a maximum noise level of 78 dB in the cab. Specific equipment includes a reversing camera, window tinting, steel bullbar, UHF unit, LED driving lights, 12V accessory outlets, tow bar, steel tipping tray, canvas seat covers, and rubber floor mats. Amber beacons and LED work lights are also required, with specific mounting and wiring instructions. The successful supplier must provide a full set of parts books, workshop manuals, operator instructions, and various maintenance checklists. The vehicle's compliance plate date must be no more than 12 months prior to the delivery date, unless otherwise agreed in writing. Refuelling points must allow for safe ground-level refuelling. The tenderer must specify the oils to be used and whether the unit requires AdBlue or DPF. The vehicle must be fitted with Balonne Shire Council stickers and vehicle identification number stickers. Optional equipment includes an open cage toolbox and lockable storage drawers. The closing date for submissions is Friday, 05 June 2026, at 02:00 AM E. South America Standard Time.
The bid notice does not explicitly state a delivery deadline for the truck. However, it mentions that any vehicle supplied must have a compliance plate date no more than twelve months prior to the date of delivery, unless prior agreement has been reached in writing with Balonne Shire Council.
The bid notice states that Balonne Shire Council invites tenders from suitably qualified respondents.
The supplier query cutoff date is Friday, 05 June 2026, 02:00 AM E. South America Standard Time.
An online briefing session will be held on 28 jan, 2026 10: 00 am. The respondent is requested to confirm its attendance by no later than 2pm awst on friday 23rd january 2026 by contacting michael ansty, senior procurement manager via email at ***@***. *. * potential respondents are strongly encouraged to attend the briefing.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
90% recommend BidHits Australia (1058 real users, 08/06/2026).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
We selected helpful reviews from real users. Order may change periodically.
It is complete and optimal, it improves my time.
R. de L. Cruz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
A complete, easy-to-use system. Support from calm, patient, and clear-teaching professionals.
W. M. Da Silva
It encompasses all portals in one place.
G. Ferrea
Excellent platform to help promote and expand the reach of your work.
C. Merino
Sending job opportunities via email is very good. Their information sources are rich in opportunities. The ease of use and advanced search options also make the work easier. The great advantage is the well-organized compilation that facilitates the search for opportunities.
V. De Folga
Efficiency in search times.
R. Chavez
I liked it — very easy to navigate. It’s the best one I’ve found.
T. Brasil
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
The platform is very user-friendly.
N. Lobato
I’m absolutely delighted with the system’s performance so far. This software has exceeded all my expectations, ensuring that no crucial keyword, such as “cathodic protection” and others related, goes unnoticed. Its precision and efficiency are remarkable, providing extra peace of mind in our operations. I’m truly impressed by its effectiveness.
BidHits Australia helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00/month. All plans include the same features, and longer terms reduce the pro-rata cost. You can start with the free trial with no auto-charge.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits Australia shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits Australia now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1058 active users, conducted through 08/06/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
