Outdoor Recreation Facility/ Community Park Development/ Outdoor Recreation Specialists
Maranda Heights Playground Installation - Council are seeking the design and construction of a new playground in the Maranda Heights Estate, located in the township of Emerald, Queensland. This Request for Quote allows for creative input into designing a playful, engaging and vibrant play destination, promoting a strong sense of community, bringing all age groups together in one space. It must inspire and encourage interaction and cooperation as children learn to play together. To improve safety, comfort an
Design and construction of a new playground with a permanent shade structure in the Maranda Heights estate, Emerald, Queensland Design and construction of a new playground, supply and installation of a permanent shade structure, rubber softfall, play equipment, hard shade cover
AI helper
Council seeks design and construction of a new playground with permanent shade structure in Maranda Heights estate, Emerald, Queensland. Works must comply with Australian standards, including AS4685:2014 for playground equipment and AS4422:2016 for rubber softfall. Wind region B intermediate per AS/NZS **** completion is a hold point requiring council approval. Designs must be available for community consultation prior to award. Mandatory requirements include warranties for play equipment and shade structure, maintenance documentation, current trade licences, and CHRC Linksafe induction for all workers. Successful contractor must provide planning and building approvals. Tender closes 18 November 2026.
Warranties must be provided for play equipment and shade structure. The text states: warranties to be supplied for play equipment and shade structure and all hardware.
Contractors must provide evidence of current trade licences. The text states: evidence of current trade licences and all workers are to complete councils chrc linksafe induction of all workers.
Outdoor Recreation Facilities/ Public Park Development
**** - Peregian Beach Playground - Design and Construct - Noosa Shire Council invites tenders from suitably qualified tenderers for the design and construction of a playground at Peregian Beach Park, Kingfisher Drive, Peregian Beach as described in more detail in Part 5 - Scope. This is a lump sum contract. Budget range for this project is $ 550, 000 to $ 575, 000 ( Excluding GST). Practical Completion Date - 30 June 2027
Design and construction of a playground at Peregian Beach Park Playground design and construction
AI helper
Noosa Shire Council invites tenders for design and construction of a playground at Peregian Beach Park. Lump sum contract. Budget range $550,****,000 excluding GST. Practical completion by 30 June 2027. Tenders due 19 November 2026 at 2:00pm AEST via VendorPanel. Optional site inspection on 3 November 2026, RSVP by 2 November. Evaluation criteria include price (20%), experience (25%), methodology (30%), quality management (5%), health and safety (5%), environment management (5%), sustainability (5%), local economy (5%). Tenders valid 90 days. Communications via VendorPanel, cutoff 14 November 2026.
Practical completion is required by 30 June 2027. The notice states: practical completion date 30 june 2027.
Evaluation criteria include price (20%), experience and capability (25%), methodology (30%), quality management systems (5%), health and safety (5%), environment management systems (5%), environment sustainability (5%), and contribution to local economy (5%).
Tenderers must be suitably qualified. The notice states: invites tenders from suitably qualified tenderers for the design and construction of a playground.
An optional site inspection is scheduled. The notice states: briefing or site inspection: 11:00am 12:00pm on tuesday 3 november 2026 and maximum attendees 2 per organisation.
Communications regarding the procurement process must be submitted via VendorPanel. The notice states: no later than five 5 calendar days prior to the time stated in item 4.
Council may exclude a response if respondents canvass councillors or employees. The notice states: council may exclude a response from assessment if the respondent does not comply with this requirement.
The budget range is stated as $550,000 to $575,000 (excluding GST).
Outdoor Recreation Facility/ Community Park Development
Maranda Heights Playground Installation - Council are seeking the design and construction of a new playground in the Maranda Heights Estate, located in the township of Emerald, Queensland. This Request for Quote allows for creative input into designing a playful, engaging and vibrant play destination, promoting a strong sense of community, bringing all age groups together in one space. It must inspire and encourage interaction and cooperation as children learn to play together. To improve safety, comfort an
Design and construction of a new playground with a permanent shade structure in the Maranda Heights Estate, Emerald, Queensland Design and construction of a new playground; supply and installation of a permanent shade structure; rubber softfall; play equipment; hard shade cover
AI helper
Council seeks design and construction of a new playground with permanent shade structure in Maranda Heights Estate, Emerald, QLD. Works must comply with Australian standards, including AS4685:2014 for playground equipment and AS4422:2016 for rubber softfall. Wind region B intermediate per AS/NZS **** completion is a hold point requiring council approval and community consultation. Mandatory requirements include warranties, maintenance documentation, trade licences, and CHRC Linksafe induction. Tender closes 18 November 2026.
Warranties must be supplied for play equipment and shade structure. The contract states: warranties to be supplied for play equipment and shade structure and all hardware.
Contractor must provide evidence of current trade licences and all workers are to complete councils chrc linksafe induction.
Outdoor Recreation Facilities/ Public Park Development
**** - Peregian Beach Playground - Design and Construct - Noosa Shire Council invites tenders from suitably qualified tenderers for the design and construction of a playground at Peregian Beach Park, Kingfisher Drive, Peregian Beach as described in more detail in Part 5 - Scope. This is a lump sum contract. Budget range for this project is $ 550, 000 to $ 575, 000 ( Excluding GST). Practical Completion Date - 30 June 2027
Design and construction of a playground at Peregian Beach Park Playground design and construction
AI helper
Noosa Shire Council invites tenders for design and construction of a playground at Peregian Beach Park, Kingfisher Drive, Peregian Beach QLD. Lump sum contract. Budget range $550,****,000 excluding GST. Practical completion by 30 June 2027. Tenders due 2:00pm AEST 19 November 2026 via VendorPanel. Optional site inspection on 3 November 2026, RSVP by 2 November 2026. Evaluation criteria include price (20%), experience (25%), methodology (30%), quality management (5%), health and safety (5%), environment management (5%), sustainability (5%), local economy contribution (5%). Tenders valid 90 days. Communications via VendorPanel, cutoff 14 November 2026.
Practical completion is required by 30 June 2027. The notice states: practical completion date 30 june 2027.
Evaluation criteria include price (20%), experience and capability (25%), methodology (30%), quality management systems (5%), health and safety (5%), environment management systems (5%), environment sustainability (5%), and contribution to local economy (5%).
Council invites tenders from suitably qualified tenderers for the design and construction of the playground.
An optional site inspection is scheduled: 11:00am 12:00pm on tuesday 3 november 2026 at Peregian Beach Park. RSVP required by 2 November 2026.
Respondents must not canvass or communicate with councillors or employees except as provided in Part 3. Council may exclude a response if this requirement is not complied with.
The budget range is stated as $550,000 to $575,000 (excluding GST).
Outdoor Recreation Facility/ Play Space Development
**** - Peregian Beach Playground - Design and Construct - Noosa Shire Council invites tenders from suitably qualified tenderers for the design and construction of a playground at Peregian Beach Park, Kingfisher Drive, Peregian Beach as described in more detail in Part 5 - Scope. This is a lump sum contract. Budget range for this project is $ 550, 000 to $ 575, 000 ( Excluding GST). Practical Completion Date - 30 June 2027
Design and construction of a playground at Peregian Beach Park Playground design and construction
AI helper
Noosa Shire Council invites tenders for design and construction of a playground at Peregian Beach Park. Lump sum contract. Budget range $550,****,000 excluding GST. Tenders due 19 November 2026 via VendorPanel. Optional site inspection on 3 November 2026, RSVP by 2 November. Evaluation criteria include price (20%), experience (25%), methodology (30%), quality, safety, environment, and local economy. Practical completion by 30 June 2027. Tenders valid 90 days. Communications via VendorPanel, cutoff 14 November 2026.
Practical completion is required by 30 June 2027. The notice states: practical completion date 30 june 2027.
Evaluation criteria include price (20%), experience and capability (25%), methodology (30%), quality management systems (5%), health and safety (5%), environment management systems (5%), environment sustainability (5%), and contribution to local economy (5%).
Tenderers must be suitably qualified. The notice states: invites tenders from suitably qualified tenderers for the design and construction of a playground.
An optional site inspection is scheduled. The notice states: briefing or site inspection: 11:00am 12:00pm on tuesday 3 november 2026 and maximum attendees 2 per organisation optional.
Communications regarding the procurement process must be submitted via VendorPanel. The notice states: no later than five 5 calendar days prior to the time stated in item 4.
Respondents must not canvass councillors or employees. The notice states: council may exclude a response from assessment if the respondent does not comply with this requirement.
The budget range is stated as $550,000 to $575,000 (excluding GST).
We selected helpful reviews from real users. Order may change periodically.
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
M. F. Cortez
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
It is complete and optimal, it improves my time.
R. de L. Cruz
Excellent information. Just what I was looking for.
L. H. Borrelli
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I liked the way they search for tenders and provide us with the link to view them.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Plans start at A$ 30.00/month, with options for different needs and subscription terms. Plans are prepaid: check the total amount and duration before confirming. Start with the free trial and assess the results before subscribing, with no automatic charges.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
