Asphalt Strength Tenders

Submissions close on 7th August 2026 at 2pm AWST. Respondents must allow sufficient time to upload documents into VendorPanel before the closing date and time.

Submissions will be assessed against qualitative criteria, with the most suitable respondents shortlisted. The aggregate score of each submission will be used as one of the factors in the final assessment of the qualitative criteria and in the overall assessment of value for money.

Respondents must be suitably qualified and experienced construction contractors. Eligibility to participate in the RFT will be restricted to providers who comply with the EOI provisions and are accepted by the CEO to be placed on a prequalified shortlist. Key criteria include relevant project experience, key personnel, resourcing and capacity, safety, quality and environmental management, project understanding and delivery approach, and commercial and financial capacity.

The most suitable respondents may be required to make a presentation and/or open premises for inspection.

Submissions may be rejected if not submitted before the deadline, not submitted at the specified place (VendorPanel portal), or if they fail to comply with any other requirements of the EOI. Files found to contain viruses may be excluded. Canvassing of officials may lead to omission from consideration.

The tender closes on Wednesday, 29 July 2026, at 01:00 AM E. South America Standard Time. The expected decision date is Wednesday, 09 September 2026.

Payments under the contract will be made at Rockhampton, Queensland. The contract specifies times for payment claims, with claims generally due by the 15th of each month, subject to satisfaction of certain preconditions.

The contractor warrants that they are skilled in similar projects, will carry out works with due diligence and skill, use the best available materials, have a competent organisation, hold the necessary licenses, and comply with privacy laws. These warranties survive the final certificate.

Contractors must be suitably qualified and experienced. Specific qualifications and experience requirements are detailed within the tender documents, including adherence to Australian Standards and relevant legislation.

Liquidated damages are set at $2,000 per day for delays to practical completion, with no limit specified for these damages.

A pre-start meeting is mandatory before commencing works on site. This meeting will address construction and site-specific issues, lines of communication, and site induction.

The supplier query cutoff date is Monday, 27 July 2026, at 01:00 AM E. South America Standard Time.

The contract outlines conditions for substantial breach, which could lead to disqualification or termination. This includes failure to act honestly, breaches of contract, or insolvency events.

The tender closes on Wednesday, 29 July 2026 at 01:00 AM.

The contractor warrants that the works will be constructed in accordance with all design documents and will comprise the best available materials, be of good and merchantable quality, free from latent defects, and fit for their intended purpose.

Suitably qualified and experienced contractors are invited to submit a tender.

Supplier queries have a cutoff of Monday, 27 July 2026 at 01:00 AM.

The tender closes on Wednesday, 29 July 2026 at 01:00 AM E. South America Standard Time.

Payments under the contract shall be made at Rockhampton, Queensland. The contract specifies payment claim timelines and interest rates on overdue payments as per the Queensland Building and Construction Commission Act.

The contractor warrants that they are skilled in similar projects, will carry out works with due diligence and skill, use the best available materials, have a competent organisation, hold the appropriate QBCC license, and comply with privacy legislation.

Contractors must be suitably qualified and experienced. Specific qualifications and experience requirements are detailed within the tender documents.

Liquidated damages are set at $2,000 per day for delays to practical completion, with an unlimited limit.

A pre-start meeting is mandatory before commencing works on site, where the contractor must satisfy the superintendent on various requirements, including insurances and security.

Supplier queries have a cutoff date of Monday, 27 July 2026 at 01:00 AM E. South America Standard Time.

The contract outlines conditions for excluded persons, including those convicted of indictable offences or who have suffered an event of insolvency, which could lead to disqualification.

The tender closes on Wednesday, 22 July 2026 at 01:00 AM E. South America Standard Time.

The contractor warrants that the works will be constructed in accordance with all design documents and will comprise the best available materials, be of good and merchantable quality, free from latent defects, and fit for their intended purpose.

Suitably qualified and experienced contractors are invited to submit a tender.

Supplier queries have a cutoff of Monday, 20 July 2026 at 01:00 AM E. South America Standard Time.