Supply and construct a sewer rising main at Texas Apex Park, including underbore across Inglewood Texas Rd. Tender closes 4pm EST 30 October 2026. Lump sum contract, prices inclusive of GST. Completion required by 24 June 2027. No mandatory site visit, but requests welcome. Tenderers must price both Alternative A (enveloper pipe) and Alternative B (direct installation). Submissions via Vendor Panel. Evaluation based on price, past performance, technical expertise, WHS systems, availability, and local contractor status. 12-month workmanship warranty required.
Completion of all works, including commissioning, is required by 24 June 2027. As stated: completion of all components of the works, including commissioning, is required by 24 june 2027.
Progress claims may be submitted for completed works, with payments up to 80% of the contract sum. The remaining 20% is payable upon completion and acceptance of specified deliverables. As stated: council will make payments for completed works up to a maximum of 80 of the contract sum until the works are completed.
The contractor must provide a 12-month warranty on all workmanship from the date of practical completion. As stated: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
Contractors must be suitably qualified, experienced and resourced. Submissions are assessed on tendered prices, past performance, technical expertise, WHS systems, availability, and local contractor status. As stated: submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.
Failure to maintain progress may result in liquidated damages. As stated: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages or other applicable contractual remedies.
There is no mandatory site visit, but requests are welcome. As stated: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
Any direct contact with council employees, councillors, or consultants outside the approved channel will result in automatic disqualification. As stated: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
