**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
AI helper
Tenders invited for replacement of existing elevated walkway to weir tower, including demolition of existing structural steel walkway, platform and handrails, and remediation of steel trestles via abrasive blasting and painting. Contract is lump sum or schedule of rates per **** completion due 25 March 2027. Liquidated damages $500 per day. Defects liability period 12 months. Security: two unconditional bank guarantees at 5% of contract sum. Public liability insurance minimum $20,000,000. Contact Paul Weston at 07 **** **** closes 24 November 2026.
Practical completion is due by 25th March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts. The contract states: payment period means: if the contract is a building contract, 15 business days.
Tenders are invited from suitably qualified respondents and the contract requires standard risk prequalified suppliers for the weir tower access walkway replacement project.
Liquidated damages are set at $500 per day for delay, as stated in the annexure: liquidated damages, rate subclause 34. 7 500 per day.
**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
AI helper
Charters Towers Regional Council invites tenders for replacement of existing elevated walkway to access weir tower during flood events. Works include demolition of existing structural steel walkway, platform and handrails, and remediation of existing steel trestles via abrasive blasting and painting. Contract is construct only, lump sum, with practical completion by 25 March 2027. Tender closes 24 November 2026. Contact Paul Weston at 07 **** ****.
Practical completion is due by 25th March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts, as stated: payment period means: 1. if the contract is a building contract, 15 business days.
Tenders are invited from suitably qualified respondents to complete the works, as stated: invites tenders from suitably qualified respondents to complete the works required.
Liquidated damages are set at $500 per day, as stated: liquidated damages, rate subclause 34. 7 500 per day.
Supplier query cutoff is Thursday 19 November 2026, as stated: supplier query cutoff thursday 19 november 2026 04: 00 am.
Contractor must not engage in improper conduct, including collusive tendering or anticompetitive conduct, as stated: engaging in any collusive tendering, anticompetitive conduct, or any other unlawful or unethical conduct.
MWD - CN- **** - Asphalt Works on Peak Downs Highway 33B ( Eton Range) - DEPARTMENT OF TRANSPORT AND MAIN ROADS SKID RESISTANCE TREATMENT PROGRAM 2026/27 Project No: **** Contract Number: CN- **** Tenders are invited to tender for the skid resistance treatment program on the below locations Peak Downs Highway ( 33B). o Eton Range ( Ch **** - ****) Major works include Micro Milling. The prequalification Level applying to the Contract is F2. Tenderers are advised that the Queensland Charter for
AI helper
Tenders invited for skid resistance treatment program on Peak Downs Highway (33B) Eton Range. Major works include micro milling. Prequalification level F2 applies. Queensland Charter for Local Content, Building Code 2016 and Queensland Code apply. Electronic submission via basetender website. Tender closes 2:00pm Thursday 19 November 2026. Supplier query cutoff Tuesday 17 November 2026. Contact Buddika Athauda or Columbine C Durie.
The prequalification level applying to the contract is F2. the prequalification level applying to the contract is f2
Electronic submissions cannot be received or uploaded after the tender close time. electronic submissions cannot be received or uploaded after the tender close time
Notice of Intended Procurement - Supplementary Shipping Services - Notice of Intended Procurement - Supplementary Shipping Services- This is a pre- release notice only to provide advance notification that the Australian Antarctic Division ( AAD) of the Department of Climate Change, Energy, the Environment and Water ( DCCEEW) anticipates that it intends to commence a single stage, open tender process in Q2 of the 2026- 27 financial year for the provision of supplementary shipping services in support of the A
Supplementary shipping services for Antarctic infrastructure renewal program Provision of a suitable cargo vessel and crew, maritime transport of Commonwealth cargo between Australia and Davis Research Station Antarctica, ship- to- shore cargo transfer capability including support watercraft barges or other suitable logistics solutions, cargo handling and discharge services, voyage planning and logistics support, associated maritime services
AI helper
Pre-release notice for a single stage open tender for supplementary shipping services to support Davis critical infrastructure works under the Antarctic Infrastructure Renewal Program. Scope includes cargo vessel and crew, maritime transport between Australia and Davis Station, ship-to-shore cargo transfer, cargo handling, voyage planning and associated maritime services. Approach to market expected before end of November 2026, voyage during **** Antarctic season. Enquiries to ***@***. *. * planned procurements subject to revision or cancellation.
We selected helpful reviews from real users. Order may change periodically.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
Good information. All the information is very good!
J. A. Tellez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
M. F. Cortez
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
It encompasses all portals in one place.
G. Ferrea
It's an extremely useful tool.
M. M. Alv
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
